Loading...
HomeMy WebLinkAbout2016-092 Contract - Quality Fence Company Contract for GOODS AND SERVICES Less than $25,000 CITY OF CONTRACTOR: QUALITY FENCE COMPANY -AS H LAND CONTACT: JASON 20 East Main Street Ashland, Oregon 97520 ADDRESS: P.O. BOX 3985 CENTRAL POINT OR 97502 Telephone: 541/488-6002 Fax: 541/488-5311 TELEPHONE: 541-664-2281 DATE AGREEMENT PREPARED: FAX: 541-664-2949 BEGINNING DATE: 4-18-16 COMPLETION DATE: 4-30-16 COMPENSATION: $ 1,895.00 GOODS AND SERVICES TO BE PROVIDED: REPAIR OR REPLACE DAMAGED AREAS OF FENCE AT THE DRINKING V1/ATER PLANT AS PER ATTACHED QUOTE. ADDITIONAL TERMS: In the event of conflicts or discrepancies among the contract documents, the City of Ashland Contract for Goods and Services will be primary and take precedence, and any exhibits or ancillary contracts or agreements having redundant or contrary provisions will be subordinate to and interpreted in a manner that will not conflict with the said primary City of Ashland Contract. NOW THEREFORE, pursuant to AMC 2.50.090 and after consideration of the mutual covenants contained herein the CITY AND CONTRACTOR AGREE as follows.- 1 . All Costs by Contractor: Contractor shall, provide all goods as specified above and shall at its own risk and expense, perform any work described above and, unless otherwise specified, furnish all labor, equipment and materials required for the proper performance of such work. 2. Qualified Work: Contractor has represented, and by entering into this contract now represents, that any personnel assigned to the work required under this contract are fully qualified to perform the work to which they will be assigned in a skilled and worker-like manner and, if required to be registered, licensed or bonded by the State of Oregon, are so registered, licensed and bonded. Contractor must also maintain a current City business license. 3. Completion Date: Contractor shall provide all goods in accordance with the standards and specifications, no later than the date indicated above and start performing the work under this contract by the beginning date indicated above and complete the work by the completion date indicated above. 4. Compensation: City shall pay Contractor for the specified goods and for any work performed, including costs and expenses, the sum specified above. Payments shall be made within 30 days of the date of the invoice. Should the contract be prematurely terminated, payments will be made for work completed and accepted to date of termination. Compensation under this contract, including all costs and expenses of Contractor, is limited to $25,000.00, unless a separate written contract is entered into by the City. 5. Ownership of Documents: All documents prepared by Contractor pursuant to this contract shall be the property of City. 6. Statutory Requirements: ORS 27913.220, 27913.225, 27913.230, 27913.235, ORS Chapter 244 and ORS 670.600 are made part of this contract. 7. Living Wage Requirements: If contractor is providing services under this contract and the amount of this contract is $20,142.20 or more, Contractor is required to comply with chapter 3.12 of the Ashland Municipal Code by paying a living wage, as defined in this chapter, to all employees performing work under this contract and to any subcontractor who performs 50% or more of the work under this contract. Contractor is also required to post the notice attached hereto as Exhibit B predominantly in areas where it will be seen by all employees. 8. Indemnification: Contractor agrees to defend, indemnify and save City, its officers, employees and agents harmless from any and all losses, claims, actions, costs, expenses, judgments, subrogations, or other damages resulting from injury to any person (including injury resulting in death), or damage (including loss or destruction) to property, of whatsoever nature arising out of or incident to the performance of this contract by Contractor (including but not limited to, Contractor's employees, agents, and others designated by Contractor to perform work or services attendant to this contract). Contractor shall not be held responsible for any losses, expenses, claims, subrogations, actions, costs, judgments, or other damages, directly, solely, and proximately caused by the negligence of City. 9. Termination: a. Mutual Consent. This contract may be terminated at any time by mutual consent of both parties. b. City's Convenience. This contract may be terminated at any time by City upon 30 days' notice in writing and delivered b certified mail or in person. Contract for Goods and Services Less than $25,000, Revised 06/02/2015, Page 1 of 5 C. For Cause. City may terminate or modify this contract, in whole or in part, effective upon delivery of written notice to Contractor, or at such later date as may be established by City under any of the following conditions: i. If City funding from federal, state, county or other sources is not obtained and continued at levels sufficient to allow for the purchase of the indicated quantity of services; ii. If federal or state regulations or guidelines are modified, changed, or interpreted in such a way that the services are no longer allowable or appropriate for purchase under this contract or are no longer eligible for the funding proposed for payments authorized by this contract; or iii. If any license or certificate required by law or regulation to be held by Contractor to provide the services required by this contract is for any reason denied, revoked, suspended, or not renewed. d. For Default or Breach. i. Either City or Contractor may terminate this contract in the event of a breach of the contract by the other. Prior to such termination the party seeking termination shall give to the other party written notice of the breach and intent to terminate. If the party committing the breach has not entirely cured the breach within 15 days of the date of the notice, or within such other period as the party giving the notice may authorize or require, then the contract may be terminated at any time thereafter by a written notice of termination by the party giving notice. ii. Time is of the essence for Contractor's performance of each and every obligation and duty under this contract. City by written notice to Contractor of default or breach, may at any time terminate the whole or any part of this contract if Ccntractor fails to provide services called for by this contract within the time specified herein or in any extension thereof. iii. The rights and remedies of City provided in this subsection (d) are not exclusive and are in addition to any other rights and remedies provided by law or under this contract. e. Obligation/Liability of Parties. Termination or modification of this contract pursuant to subsections a, b, or c above shall be without prejudice to any obligations or liabilities of either party already accrued prior to such termination or modification. However, upon receiving a notice of termination (regardless whether such notice is given pursuant to subsections a, b, c or d of this section, Contractor shall immediately cease all activities under this contract, unless expressly directed otherwise by City in the notice of termination. Further, upon termination, Contractor shall deliver to City all contract documents, information, works-in-progress and other property that are or would be deliverables had the contract been completed. City shall pay Contractor for work performed prior to the termination date if such work was performed in accordance with the Contract. 10. Independent Contractor Status: Contractor is an independent Contractor and not an employee of the City. Contractor shall have the complete responsibility for the performance of this contract. 11. Non-discrimination Certification: The undersigned certifies that the undersigned Contractor has not discriminated against minority, women or emerging small businesses enterprises in obtaining any required subcontracts. Contractor further certifies that it shall not discriminate in the award of such subcontracts, if any. The Contractor understands and acknowledges that it may be disqualified from bidding on this contract, including but not limited to City discovery of a misrepresentation or sham regarding a subcontract or that the Bidder has violated any requirement of ORS 279A.110 or the administrative rules implementing the Statute. 12. Asbestos Abatement License: If required under ORS 468A.710, Contractor or Subcontractor shall possess an asbestos abatement license. 13. Assignment and Subcontracts: Contractor shall not assign this contract or subcontract any portion of the work without the written consent of City. Any attempted assignment or subcontract without written consent of City shall be void. Contractor shall be fully responsible for the acts or omissions of any assigns or subcontractors and of all persons employed by them, and the approval by City of any assignment or subcontract shall not create any contractual relation between the assignee or subcontractor and City. 14. Use of Recyclable Products: Contractor shall use recyclable products to the maximum extent economically feasible in the performance of the contract work set forth in this document. 15. Default. The Contractor shall be in default of this agreement if Contractor: commits any material breach or default of any covenant, warranty, certification, or obligation it owes under the Contract; if it loses its QRF status pursuant to the QRF Rules or loses any license, certificate or certification that is required to perform the work or to qualify as a QRF if Contractor has qualified as a QRF for this agreement; institutes an action for relief in bankruptcy or has instituted against it an action for insolvency; makes a general assignment for the benefit of creditors; or ceases doing business on a regular basis of the type identified in its obligations under the Contract; or attempts to assign rights in, or delegate duties under, the Contract. 16. Insurance. Contractor shall at its own expense provide the following insurance: a. Worker's Compensation insurance in compliance with ORS 656.017, which requires subject employers to provide Oregon workers' compensation coverage for all their subject workers b. General Liability insurance with a combined single limit, or the equivalent, of not less than Enter one: $200,000, $500,000, $1,000,000, $2,000,000 or Not Applicable for each occurrence for Bodily Injury and Property Damage. C. Automobile Liabilit insurance with a combined single limit, or the equivalent, of not less than Enter one: Contract for Goods and Services Less than $25,000, Revised 06/02/2015, Page 2 of 5 $200,000, $500,000, $1,000,000, or Not Applicable for each accident for Bodily Injury and Property Damage, including coverage for owned, hired or non-owned vehicles, as applicable. d. . Notice of cancellation or change. There shall be no cancellation, material change, reduction of limits or intent not to renew the insurance coverage(s) without 30 days' written notice from the Contractor or its insurer(s) to the City. e. Additional Insured/Certificates of Insurance. Contractor shall name The City of Ashland, Oregon, and its elected officials, officers and employees as Additional Insureds on any insurance policies required herein but only with respect to Contractor's services to be provided under this Contract. As evidence of the insurance coverages required by this Contract, the Contractor shall furnish acceptable insurance certificates prior to commencing work under this contract. The contractor's insurance is primary and non-contributory. The certificate will specify all of the parties who are Additional Insureds. Insuring companies or entities are subject to the City's acceptance. If requested, complete copies of insurance policies, trust agreements, etc. shall be provided to the City. The Contractor shall be financially responsible for all pertinent deductibles, self-insured retentions and/or self- insurance. 17. Governing Law; Jurisdiction; Venue- This contract shall be governed and construed in accordance with the laws of the State of Oregon without resort to any jurisdiction's conflict of laws, rules or doctrines. Any claim, action, suit or proceeding (collectively, "the claim") between the City (and/or any other or department of the State of Oregon) and the Contractor that arises from or relates to this contract shall be brought and conducted solely and exclusively within the Circuit Court of Jackson County for the State of Oregon. If, however, the claim must be brought in a federal forum, then it shall be brought and conducted solely and exclusively within the United States District Court for the District of Oregon filed in Jackson County, Oregon. Contractor, by the signature herein of its authorized representative, hereby consents to the in personam jurisdiction of said courts. In no event shall this section be construed as a waiver by City of any form of defense or immunity, based on the Eleventh Amendment to the United States Constitution, or otherwise, from any claim or from the jurisdiction. 18. THIS CONTRACT AND ATTACHED EXHIBITS CONSTITUTE THE ENTIRE AGREEMENT BETWEEN THE PARTIES. NO WAIVER, CONSENT, MODIFICATION OR CHANGE OF TERMS OF THIS CONTRACT SHALL BIND EITHER PARTY UNLESS IN WRITING AND SIGNED BY BOTH PARTIES. SUCH WAIVER, CONSENT, MODIFICATION OR CHANGE, IF MADE, SHALL BE EFFECTIVE ONLY IN THE SPECIFIC INSTANCE AND FOR THE SPECIFIC PURPOSE GIVEN. THERE ARE NO UNDERSTANDINGS, AGREEMENTS, OR REPRESENTATIONS, ORAL OR WRITTEN, NOT SPECIFIED HEREIN REGARDING THIS CONTRACT. CONTRACTOR, BY SIGNATURE OF ITS AUTHORIZED REPRESENTATIVE, HEREBY ACKNOWLEDGES THAT HE/SHE HAS READ THIS CONTRACT, UNDERSTANDS IT, AND AGREES TO BE BOUND BY ITS TERMS AND CONDITIONS. 19. Nonappropriations Clause. Funds Available and Authorized: City has sufficient funds currently available and authorized for expenditure to finance the costs of this contract within the City's fiscal year budget. Contractor understands and agrees that City's payment of amounts under this contract attributable to work performed after the last day of the current fiscal year is contingent on City appropriations, or other expenditure authority sufficient to allow City in the exercise of its reasonable administrative discretion, to continue to make payments under this contract. In the event City has insufficient appropriations, limitations or other expenditure authority, City may terminate this contract without penalty or liability to City, effective upon the delivery of written notice to Contractor, with no further liability to Contractor. 20. Prior Approval Required Provision. Approval by the City of Ashland Council or the Public Contracting Officer is required before any work may begin under this contract. 21. Certification. Contractor shall sign the certification attached hereto as Exhibit A and herein incorporated by reference. Contractor: City of Ashland 1 i ZNLO By By Signature Department ead Print Name Print Name Title Date W-9 One copy of a W-9 is to be submitted with the signed contract. Purchase Order No. Contract for Goods and Services Less than $25,000, Revised 06/02/2015, Page 3 of 5 EXHIBIT A CERTIFICATIONS/REPRESENTATIONS: Contractor, under penalty of perjury, certifies that (a) the number shown on the attached W-9 form is its correct taxpayer ID (or is waiting for the number to be issued to it and (b) Contractor is not subject to backup withholding because (i) it is exempt from backup withholding or (ii) it has not been notified by the Internal Revenue Service (IRS) that it is subject to backup withholding as a result of a failure to report all interest or dividends, or (iii) the IRS has notified it that it is no longer subject to backup withholding. Contractor further represents and warrants to City that (a) it has the power and authority to enter into and perform the work, (b) the Contract, when executed and delivered, shall be a valid and binding obligation of Contractor enforceable in accordance with its terms, (c) the work under the Contract shall be performed in accordance with the highest professional standards, and (d) Contractor is qualified, professionally competent and duly licensed to perform the work. Contractor also certifies under penalty of perjury that its business is not in violation of any Oregon tax laws, and it is a corporation authorized to act on behalf of the entity designated above and authorized to do business in Oregon or is an independent Contractor as defined in the contract documents, and has checked four or more of the following criteria: (1) 1 carry out the labor or services at a location separate from my residence or is in a specific portion of my residence, set aside as the location of the business. (2) Commercial advertising or business cards or a trade association membership are purchased for the business. (3) Telephone listing is used for the business separate from the personal residence listing. ' (4) Labor or services are performed only pursuant to written contracts. (5) Labor or services are performed for two or more different persons within a period of one year. (6) 1 assume financial responsibility for defective workmanship or for service not provided as evidenced by the ownership of performance bonds, warranties, errors and omission insurance or liability insurance relating to the labor or services to be provided. Contractor (Date) Contract for Goods and Services Less than $25,000, Revised 06/02/2015, Page 4 of 5 CITY • ASHLAND- • • EXHIBIT B City of Ashland LIVING GE f- • - - per hour effective 1W June 30, 2015 portion of business of their 401 K and IRS eligible _ employer, if the employer has cafeteria plans (including ten or more employees, and childcare) benefits to the has received financial amount of wages received by assistance for the project or the employee. Y For all hours worked undera business from the City of service contract between their Ashland in excess of ~ Note: "Employee" does not employer and the City of $20,142.20. include temporary or part-time Ashland if the contract employees hired for less than exceeds $20,142.20 or more, If their employer is the City of 1040 hours in any twelve- Ashland including the Parks month period. For more - For all hours worked in a and Recreation Department. details on applicability of this month if the employee spends policy, please see Ashland 50% or more of the = In calculating the living wage, Municipal Code Section employee's time in that month employers may add the value 3,12.020. working on a project or of health care, retirement, Call the Ashland City Administrator's office at 541-488-6002 or write to the City Administrator, City Hall, 20 East Main Street, Ashland, OR 97520 or visit the city's website at www.ashland.or.us. Notice to Employers: This notice must be posted predominantly in areas where it can be seen by all employees. C I T Y OF -ASH LAN D Contract for Goods and Services Less than $25,000, Revised 06/02/2015, Page 5 of 5 ~f 9QUALFE OP ID: KD ACORO CERTIFICATE OF LIABILITY INSURANCE 091291201 FD YY) 5 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER- THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the policy(ies) must be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement s). CONTACT PRODUCER Phone: 541-779-4232 N AME: Hart Insurance - - - - - PHONE - 1123 Royal Ave. Fax: 541-772-3963 A/q o E:t : ~aC No): Medford, OR 97504 E-MAIL Hart Insurance (Medford ADDRESS.-- - r - - INSURER(S) AFFORDING COVERAGE NAIC INSURER A : SAIF Corp INSURED Quality Fence Co. INSURERS: a: Reliable Electric -i----~-~ - - ~ - - INSURER C P.O. Box 3985 Central Point, OR 97502-3985 INSURER ° INSURER E INSURER F : COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS rO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. ILTR TYPE OF INSURANCE DDL SUB POLICY NUMBER 4 MM DD//YYYY MM DD/YYYY LIMITS LTR GENERAL LIABILITY I EACH OCCURRENCE $ _ _ COMMERCIAL GENERAL LIABILITY A E ENT D PREMISES (Ea occurrencef $ I CLAIMS-MADE F OCCUR MED EX_P (Any one person) $ - PERSONAL 8 ADV INJURY $ GENERAL AGGREGATE $ GEN'L AGGREGATE LIMIT APPLIES PER I PRODUCTS - COMP/OP AGG $ r POLICY PRO I LOC I $ JECT AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT -1 i Ea accident _ ANY AUTO BODILY INJURY (Per person) $ ALL OWNED SCHEDULED BODILY INJURY (Per accident) $ AUTOS _ AUTOS NON-OWNED I —PROPERTY -DAMAGE - HIRED AUTOS _ AUTOS Perawa enl $ - - - UMBRELLA LIAR T-~ OCCUR EACH OCCURRENCE $ __J EXCESS LIAB CLAIMS-MADE AGGREGATE---- $ - - DED , RETENTION $ I $ WORKERS COMPENSATION X WC STATU- OTH AND EMPLOYERS' LIABILITY YIN A ANY PROPRIETOR/PARTNER/EXECUTIVE 738638 10/01/2014 10/0112015 EL EACH ACCIDENT $ 500,00 OFFICER/MEMBER EXCLUDED? N/A r - - - - (Mandatory in NH) 738638 10101/2015 10101/2016 I E, L. DISEASE - EA EMPLOYEEI $ 500,00 It yes, describe under - - - DESCRIPTION OF OPERATIONS below E.L DISEASE -POLICY LIMIT _1 $ 500,00 1 ~ I DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES )Attach ACORD 101, Additional Remarks Schedule, if more space Is required) CERTIFICATE HOLDER CANCELLATION CITYASH SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Ashland ACCORDANCE WITH THE POLICY PROVISIONS. 20 E Main Street AUTHORIZED REPRESENTATIVE Ashland, OR 97520 Hart Insurance / Medford ©1988-2010 ACORD CORPORATION. All rights reserved. ACORD 25 (2010105) The ACORD name and logo are registered marks of ACORD Qshlcy so$_ PROPOSAL QUALITY FENCE COMPANY CCB # 8936 Find us also at: 497 SW Union Avenue 114 W. Pine Street (541) 664-2281 Grants Pass, OR 97527 1d0 JOB TOO LARGE PO Box 3985 1-800-451-8883 2077 NE Diamond Lake Blvd. ...NO JOB TOO SMALL Central Point, OR 97502 Fax: (541) 664-2949 Roseburg, OR 97470 PROPOSAL SUBMITTED TO PHONE DATE Ashland Drinking Water Plant March 2, 2016 STREET JOB NAME 1400 Granite Street CITY, STATE AND ZIP CODE JOB LOCATION Ashland, OR 97520 ATTENTION EMAIL CELL PHONE Greg Hunter areg.hunter(aDashland.or.us We hereby submit specifications and estimate for: Repair tree damaged fence in 3 locations to include but not limited to: • Replace 3 damaged posts • Straighten 4 existing posts • Replace 55' of 8' high 11 gauge galvanized chain link fabric • Replace 10 barb arms • Re-stretch barb wire and bottom tension wire TOTAL $1,895.00 Note: Owner has 6' high chain link fabric if needed in one location. We Propose hereby to furnish materials and labor--complete in accordance with above specifications, for the sum of ONE THOUSAND EIGHT HUNDRED NINTY-FIVE AND NO/100---------------------------------------------------- $1895.00 ayment to be made as o ov,. PAYMENT ON COMPLETION All material is guaranteed to be as specified. All work to be completed In a workmanlike manner according to Authorized standard practices. Any alteration or deviation from above specifications involving extra costs will be executed only upon written orders, and will become an extra charge over and above the estimale, All agreements contingent upon Signature strikes, accidents or dlays beyond our control. Owner to carry fire, tornado and other necessary insurance. Our workers are fully covered by workmen's Compensation insurance. This proposal is also subject to all terms and Jason Shoemaker ,fah conditions contained on the reverse side hereof. ote: This proposal may be withdrawn by us if not accepted within 14 days Acceptance of Proposal--All prices, specifications and conditions are satisfactory and are hereby accepted. You are authorized to do the work as Signature specified. Payment will be made as outlined above. I have read the entire contract and agree to its content. Note: Quality Fence Co. not responsible for any damage to anything in or Signature below the ground or concrete. This includes private water line, electrical line, sprinkler systems, etc. Your signature indicates that you fully understand the limits of Quality Fence Co. responsibility. Date of acceptance: OTHER TERMS AND CONDITIONS OF PROPOSAL: INTEREST: Interest shall accrue upon all monies due to Quality Fence Company at the rate of 18 percent per annum from the due date of such monies until paid. ATTORNEY'S FEES: In case any suit, action or proceeding is brought to enforce any of the terms or provisions of this proposal or any of the parties' rights hereunder, the losing party in such suit, action, proceeding or any appeal there from agrees to pay such sum as the court may adjudge reasonable as attorney's fees, in addition to costs and disbursements. The reasonable costs of title reports required for any legal action contemplated shall be paid by the customer. In addition, if this matter is referred to an attorney for collection, customer agrees to pay Quality Fence Company's reasonable attorney's fees incurred in any such proceeding prior to litigation being filed. th+fty Sags.--PROPOSAL . QUALITY FENCE COMPANY CCB # 8936 Find us also at: 497 SW Union Avenue 114 W. Pine Street (541) 664-2281 Grants Pass, OR 97527 -NO JOB TOO LARD PO Box 3985 1-800-451-8883 2077 NE Diamond Lake Bivd. ...NO 108 TOO SMALL Central Point, OR 97502 Fax: (541) 664-2949 Roseburg, OR 97470 PROPOSAL SUBMITTED TO PHONE DATE Ashland Drinking Water Plant March 2, 2016 STREET JOB NAME 1400 Granite Street CITY, STATE AND ZIP CODE JOB LOCATION Ashland, OR 97520 ATTENTION EMAIL CELL PHONE Greg Hunter greg.hunter .ashiand.or.us We hereby submit specifications and estimate for: Repair tree damaged fence in 3 locations to include but not limited to: • Replace 3 damaged posts ® Straighten 4 existing posts ® Replace 55' of 8' high 11 gauge galvanized chain link fabric • Replace 10 barb arms • Re-stretch barb wire and bottom tension wire TOTAL $1,895.00 Note: Owner has 6' high chain link fabric if needed in one location. We Propose hereby to furnish materials and labor--complete in accordance with above specifications, for the sum of. ONE THOUSAND EIGHT HUNDRED MINTY-L=IVE AND NO/100---------------------------------------------------------------------- $1895.00 Payment to to made at o ov PAYMENT ON COMPLETION All material is guaranteed to be as specified. All work to be campieted in a workman?ike manner according to Authorized standard practices. Any alteration or deviation from above specifications involving exra costs will be executed only upon written orders, and will become an extra charge over and above the ostimale. All agreements contingent upon Signature strikes, accidents or delays beyond our control. Owner to carry ire, tornado and other necessary insurance, our . workers are fuiy covered by Workmen's Compensation insurance. This proposal is also subjecl to all terms and Jason Shoemaker jah conditions contained on the reverse side hereof. j Note. This proposal may be withdrawn by us if not accepted within 14 days Acceptance of Proposal--All prices, specifications and conditions are satisfactory and are hereby accepted. You are authorized to do the work as Signature specified. Payment will be made as outlined above. I have read the entire contract and agree to its content. Note: Quality Fence Co. not responsible for any damage to anything in or Signature below the ground or concrete. This includes private water line, electrical line, sprinkler systems, etc. Your signature indicates that you fully understand the limits of Quality Fence Co. responsibility. Date of acceptance. Page 1 / 1 CITY OF ASHLAND DATE PO NUMBER 20 E MAIN ST. 4/11/2016 13473 ASHLAND, OR 97520 (541) 488-5300 VENDOR: 000649 SHIP TO: Ashland Water Treatment Plant QUALITY FENCE COMPANY (541) 488-5345 P O BOX 3985 ASHLAND, OR 97520 CENTRAL POINT, OR 97502 FOB Point: Ashland, Oreqon Req. No.: Terms: Payable on receipt Dept.: Req. Del. Date: Contact: Greq Hunter Special Inst: Confirming? No Quantity Unit Description Unit Price Ext. Price Repair tree damaqed fencing at Drinkinq 1,895.00 Water Plant Contract for Goods and Services Beqinninq date: 04/18/2016 Completion date: 04/30/2016 SUBTOTAL 1895.00 BILL To: Account Payable TAX 0.00 20 EAST MAIN ST FREIGHT 0.00 541-552-2010 TOTAL 1,895.00 ASHLAND, OR 97520 Account Number Project Number Amount Account Number Project Number Amount E 670.08.19.00.60235 1,895.00 VENDOR Auth ed Signature COPY FOR=G< CITY OF f~ ASHLAND REQUISITION Date of request: 3-28-16 Required date for delivery: E18-16:] Vendor Name QUALITY FENCE COMPANY Address, City, State, Zip P.O. BOX 3985 CENTRAL POINT, OR. 97502 Contact Name & Telephone Number JASON 541-664-2281 Fax Number 541-664-2949 SOURCING METHOD ❑ Exempt from Competitive Bidding ❑ Emergency ❑ Reason for exemption: ❑ Invitation to Bid (Copies on file) ❑ Form #13, Written findings and Authorization ❑ AMC 2.50 Date approved by Council: ❑ Written quote or proposal attached ® Written quote or proposal attached Attach co of council communication If council approval required, attach co of CC ❑ Small Procurement Cooperative Procurement Less than $5,000 ❑ Request for Proposal (Copies on file) ❑ State of Oregon Date approved by Council: ® Direct Award (Attach copy of council communication) Contract # F-1 Verbal/Written quote(s) or proposal(s) - ❑ State of Washington Intermediate Procurement ❑ Sole Source Contract # GOODS & SERVICES ❑ Applicable Form (#5,6, 7 or 8) ❑ Other government agency contract $5,000 to $100,000 ❑ Written quote or proposal attached Agency ❑ (3) Written quotes and solicitation attached ❑ Form #4, Personal Services $5K to $75K Contract # PERSONAL SERVICES ❑ Special Procurement Intergovernmental Agreement $5,000 to $75,000 ❑ Form #9, Request for Approval ❑ Agency ❑ Less than $35,000, by direct appointment ❑ Written quote or proposal attached Date original contract approved by Council: ❑ (3) Written proposals/written solicitation Date approved by Council: (Date) ❑ Form #4, Personal Services $5K to $75K Valid until: Date - (Attach copy of council communication) Description of SERVICES Total Cost REPAIR TREE DAMAGED FENCES AT THE DRINKING WATER PLANT. $ 1,895.00 Item # Quantity Unit Description of MATERIALS Unit Price Total Cost TOTAL COST Per attached quotelproposal $ 1,895.00 Project Number _ _ _ _ _ _ - _ _ _ Account Number 670.08.19.00.602353 Account Number Account Number 'Expenditure must be charged to the appropriate account numbers for the financials to accurately reflect the actual expenditures. IT Director in collaboration with department to approve all hardware and software purchases: IT Director Date Support -Yes /No By signing this requisition for ml certify that the City's public contracting requirements have been satisfied. Employee: Department Head: 1 (Equal to or greater than $5,000) Department Manager/Supervisor: City Administrator: (Equal to or greater than $25,000) Funds appropriated for current fiscal year YES / NO Finance Director (Equal to orgreaterthan $5,000) Date Comments: Form #3 - Requisition