Loading...
HomeMy WebLinkAbout2004-179 Contract - Ross Brothers & Co CITY OF ASHLAND CONTRACT FOR PUBLIC WORKS CONSTRUCTION Contract made this -z 6 - day of ,~,' v~ between the City of Ashland, ("City") and Ross Brothers & Company City and Contractor agree: 1. Contract Documents: This contract is made as a result of an Advertisement for Bid issued by City for the Water Street Bridge Project, Project Number 2001-.12. Contractor was awarded the bid as the lowest responsible bidder. In the event of' any inconsistencies in the terms of this contract, the contract documents defined in the Advertisement fbr Bid and Contractor's bid, this contract shall take precedence c,ver the contract documents, which shall take precedence over the bid. 2. Scope: Contractor shall begin and complete the project described in the contract documents within the time prescribed in the contract documents. The following exceptions, alterations, or modifications to the contract documents are incorporated into this contract: 3. Price: & Payment: City shall pay Contractor amounts earned under the contract. All payments will be made at the times and in the manner provided in the contract documents. 4. Bond: Contractor shall, within five days after execution of the contract and prior to doing m~y work under the contract, furnish bond to the City of Ashland in a form and with a surety satisfactory to City in the penal sum of $575,086.50 conditioned upon the faithful perfbrmance of this contract upon the part of the Contractor. o Default: A default shall occur under any of the following circumstances: 5.1 If the Contractor fails to begin the work under contract within the time specified, or fails to perform the work with sufficient workers or equipment or with sufficient materials to insure the prompt cc.mpletion of the project, or shall neglect or refuse to remove materials or perform anew such work as shall be rejected as defective or unsuitable, or shall discontinue the prosecution of the work. 5.2 If the Contractor shall become insolvent or declared bankrupt, or commit any act of bankruptcy or insolvency, or allow any final judgment to stand against the Contractor unsatisfied for a period of forty-eight (48) hours, or shall make an assignment for the benefit of creditors. 5.3 From any other cause whatsoever, shall not carry on the work. in an acceptable manner. 6. Remedies: In addition to the rights and remedies to which the City may be entitled by law for the enforcement of its rights under this contract, City shall have full power and authority, without violating this contract, to take prosecution of the work from the Contractor, and appropriate or use any or all of the materials and equipment on the ground that may be suitable and acceptable and may cause a contract for the completion of this contract according to its terms and provisions, or use such methods as required for the completion of the contract, in any acceptable manner. All costs and charges incurred by the City together with the costs of completing the work under the contract, shall be deducted from ~my money due or which shall become due the Contractor. In case the expense so incmTed by the City shall be less than the sum which would have been payable under the contract if it had been completed by the Contractor, then the Contractor shall be entitled to received the difference less any damages for delay to which the City may be entitled. In case such expense shall exceed the sum which would have been payable under the contract, the Contractor and the surety shall be liable and agree to and shall pay the City the amount of the excess with damages for delay of performance, if any. 7. Prewfiling Wage Rates: The Contractor shall pay a fee equal to one-tenth of one percent (0.1 percent) of price of this Contract. The fee shall be paid on or before the first progress payment or 60 days from the date work first begins on the Contract, whichever comes first. The fee is payable to the Bureau of Labor & Industries and shall be mailed or otherwise delivered to the Bureau at the following address: Bureau of Labor & Industries Wage & Hour Division Prevailing Wage Unit 800 N.E. Oregon Street #32 Portland OR 97232 8. Living Wage Rates: If the amount of this contract is $15,000 or more, Consultant is required to comply with chapter 3.12 of the Ashland Municipal Code by paying a living wage, as defined in this chapter, to all employees performing work under this contract and to any subcontractor who performs 50% or more of the service 'work under this contract. Consultant is also required to post the attached notice predominantly in areas where it will be seen by all employees. The Contractor shall fully comply with the provisions of ORS 279.348 through 279.365 pertaining to prevailing wage rates. CONTRACTOR Its: CITY OF ASHLAND '? ~ ~.Gjno Grim~idi A0,ff, ~ City Administrator /:,~'~/ REVIEWED AS TO CONTENT: DePal~nent Head Date: Coding: (For City use only) From: To: Date: Subject: Paula Brown Dawn Lamb 7/26/2004 5:05:38 PM Re: 'Water St Bridge Requisition use the following TOTAL - $575,086.50 260.08.12.00.704200 $299,000 260.08.~.34:~04200 $186,400 (currently $145,000 in budget for this proj today) (eligible cost in SD SDC is $260,000 - will need budget adjustment) 670.08.18.00.704200 $ 21,000 (water line replacement) 675.08.17.00.704200 $ 58,200 (sewer line work- collection portion) 675.08.17.00.704200 $ 10,500 (sewer line work- SDC related) :) Paula >>> Dawn Lamb 7/26/04 3:38:31 PM >>> Can I get the account number for the req so I can type it up and send it down to Kari please? Thanks, D CC: Mike Morrison; Paula Brown Certificate of Insurance THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER, THIS CERTIFICATE IS NOT AN INSURANCE POLICY AND DOES NOT AMEND, EXTEND, OR ALTER THE COVERAGE AFFORDED BY THE POLICIES LISTED, This is to Certify that ROSS BROS. & COMPANY, INC. 3501 BROOKLAKE RD NE SALEM OR 97303-.9'/12 I1,1,,I,,,I,,11,11,,,,,11,11,1,,I,,,I,,,11,,I,II1,,,,,,111,,I,I Liberty North vest. Member of Liberty Mutual Group P O Box 4555 Portland,, OR 97208-4555 503.23!9.5800 is, at the date of the certificatE.,, insured by the Company under the policy(les) listed below. The insurance afforded by the listed policy(les) is subject to ail their terms, exclusions and conditions and is not altered by any requirement, term or condition of any contrac+. or other document with respect to which this certificate may be issued. EXPIRATION TYPE OF POLICY DATE POLICY NUMBER LIMITS OF LIABILITY COVERAGE AFFORDED UNDER W.C. LAW OF COVERAGE AFFORDED UNDER W.C. LAW OF FOLLOWING STATES: FOLLOWING STATES: ~] WORKERS' OR COMPENSATION 10/01/2004 WC4-1NC-011542 EMPLOYERS LIABILITY LIMITS EMPLOYERS LIABII.ITY LIMITS Each Accident $ 500,000 Each Accident Disease - policy limit $ 500 ,000 Disease - policy limit $ Disease - each employee $ 500 ~000 Disease - each employee $ MARITIME COVERAGE-FOLLOWING STATES LIMIT OF LIAB.-IVIARITIME COVERAGE GENERAL LIABILITY General Aggregate $ E Commercial General Products Comp/OPS Aggregate $ Liability (Occurrence) Personal & Advertising Injury $ --'] Owner,s and Each Occurrence Contractor's Protective Fire Damage (Any one fire) $ [] Medical Expense {Any one person) $ AUTOMOBILE LIABILITY [] Any Auto CSL $ [] All owned Autos Bodily Injury (Per Person) [] Scheduled Autos Bodily Injury (Per Accident) $ [] Hired Autos Property Damage S [] Non-owned Autos [] Garage Liability OTHER LOCATION{S) OF OPERATIONS & JOB # {IF APPLICABLE)' ' DESCRIPTION OF OPERATIONS WATER STREET BRIDGE RI-'CONSTRUCTION PROJ NO. 2001-12-NOTICE OF AWARD SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING CANCELLATION: COMPANY WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED BELOW, BUT FAILURE 'lr'O MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE COMPANY, OR REPRESENTATIVES. MAILED To:CITY OF ASHLAND ENGINEERING ATTN: PAULA C BROWN 20 E MAIN ST ASHLAND OR 97520-1850 I1,1,,I,,,I,1,1,,,I,II1,,,,,,111,,I,,I,1,11,,,I,1,,I,1,,,I,1,1 CERTIFA EFS jh 7/13/2004 SALEM Marketing DATE ISSUED OFFICE ACORD., CERTIFICATE OF LIABILITY INSURANCE DATE 7/13/2004 PRODUCER (503)588-0095 R. Bauer Insurance Dick Bauer 2745 Liberty Street NE P. 0. Box 20070 Keizer, OR 97307-0070 INSURED ROSS BROS & COMPANY 3501 8R00KLAKE RD NE SALEM, OR 97303 INC THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON 'THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE !iNSURER A:LEXINGTON INSURANCE COMPANY i~NSURERB:FINANCIAL INDEMNITY COMPANY iiNSURERc~LANDMARK AMERICAN INS. C0. INSURER D:AMERICAN INTERNATIONAL SPECIALTY I INSURER E: COVERAGES THE POLICIES OF INSURANCE LISTED BF-'LOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITIE)N OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR POLICY EFFECTIVE POLICY EXPIRATION LTR TYPE OF INSURANCE POLICY NUMBER DATE (MM/DD/YY) DATE (MM/DD/YY) LIMITS O i GENERAL LIABILITY COMMERCIAL GENERAL LIABILITY __JCLAIMSMADE ~ i OCCUR ~WA STOP GAP t i; GEN'L AGGREGATE LIMIT APPLIES PER: , r PRO- ~POLCY, 1JECT ' ILOC AUTOMOBILE LIABILITY !ANY AUTO ', ,ALL OWNED AUTOS !i~ SCHEDULED AUTOS X ! HIRED AUTOS __ X~ NON-OWNED AUTOS GARAGELIABILITY __iANY AUTO EXCESS LIABILITY ~j OCCUR CLAIMS MADE iDEDUCTIBLE X i RETENTION $10,000 WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OTHER POLLUTION LIABILITY 0453227 C7777412 L. HA210055 (;PO 1957796 11/01/2003 10/28/2003 11/01/2003 11/01/200311 11/01/2004 10/28/2004 11/01/2004 11/01/2004 $1,000,000 EACH OCCURRENCE FIRE DAMAGE (Any one fire) $ 50,000 MHD EXP (Any one 3erson) $ PERSONAL & ADV INJURY $1,000,000 GENERAL AGGREGATE $ 2,000,000 , PRODUCTS- COMP/OP AGG $ 2,000,000 PROPERTY DAMAGE (Per accident) COMBINED SINGLE LIMIT (Ea accident) BODILY INJURY (Per person) BODILY INJURY (Per accident) AUTO ONLY - EA ACCIDENT EA ACC AGG OTHER THAN AUTO ONLY: $1,000,000 ,$5,ooo,ooo EACH OCCURRENCE AGGREGATE $ $5,000,000 $ ,$ I WC STATU~ lOTH- $ iTORY UMITS i ER i E.L. EAGH AGCIDENT iS , E.L. DISEASE - EA EMPLOYEEi $ i E.L. DISEASE - POJCY LIMIT LI~IT EACH LOSS $1,000,000 LIMIT AGGREGATE $1,000,000 DEDUCTIBLE $ 10,000 DESCRIPTION OF OPERATIONS/LOCATIONS~EHICLES/EXCLUSlONS ADDED BY ENDORSEMENT/SPECIAL PROVISIONS RE' WATER STREET BRIDGE RECONSTRUCTION PROJECT NO. 2001-12. CITY OF ASHLAND ON ITS BEHALF BY THE NAMED INSURED. IS ADDITIONAL INSURED AS RESPECTS WORK PERFORMED CERTIFICATE HOLDER X ADDITIONAL INSURED; INSURER LEI-rER: A CANCELLATION CITY OF ASHLAND 20 E MAIN ST ASHLAND OR 97520- r ATTN' ENGINEERING ACORD 25-S (7/97) SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY~ANY KIND UPON THE INSURER, ITS AGENTS OR © AC~RD CORPORATION 1988 ACORD., CERTIFICATE OF LIABILITY INSURANCE DATE 7/13/2004 PRODUCER (503)588-0095 R. Bauer Insurance Dick Bauer 2745 Liberty Street NE P. 0. Box 20070 Keizer, OR 97307-0070 INSURED ROSS BROS & COMPANY 3501 BROOKLAKE RD NE SALEM, OR COVERAGES 97303 INC THIS CERTIFICATE IS ISSUED AS A MAT'rER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT' AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. INSURERS AFFORDING COVERAGE INSURERA:LEXINGTON INSURANCE COMPANY iNSURER B:FINANCIAL INDEMNITY COMPANY INSURER c:LANDMARK AMERICAN INS. CO. iNSURERD:AMERICAN INTERNATIONAL SPECIALTY INSURER E: THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORI~)ED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. __ INS[ POLICY EFFECTIVE LTF TYPE OF INSURANCE POLICY NUMBER DATE (MM/DD/YY) GENERAL LIABILITY --~ COMMERCIAL GENERAL LIABILITY ~___~ CLAIMS MADE ~OCCUR WA STOP GAP GEN'L AGGREGATE LIMIT APPLIES PER: --~ POLICY j-~PRO'JECT ~-J LOC AUTOMOBILE LIABILITY __ANY AUTO ALL OWNED AUTOS SCHEDULED AUTOS X ! H~REDAUTOS ~-] NON-OWNED AUTOS AGF: LIABILITY C ~ DEDUCTIBLE tX I RETENIION $10,000 D !POLLUTION LIABILITY i:)453227 C7777412 ILHA210055 CPO 1957796 11/01/2003 10/28/2003 11/01/2003 11/01/2003 POLICY EXPIRATION DATE (MM/DD/YY) 11/01/2004 10/28/2004 11/01/2004 11/01/2004 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/EXCLUSIONS ADDED BY ENDORSEMEN~SPECIAL PROVISIONS RE: WATER STREET BRIDGE RECONSTRUCTION PROJECT NO. 2001-12. ON ITS BEHALF BY THE NAMED INSURED. LIMITS EACH OCCURRENCE $1,000,000 FIRE DAMAGE (Any one fire) $ 50,000 MHD EXP (Any one person) PERSONAL & ADV INJURY GENERAL AGGREGATE PRODUCTS - COMIP/OP AGG $ $1,000,000 $2,000,000 $2,000,000 PROPERTY DAMAGE (Peraccident) COMBINED SINGLE LIMIT 1 000 (Ed accident) , wv, BODILY INJURY (Per person) BODILY INJURY (Per accident) $ AUTO ONLY - EA ACCIDENT EA ACC AGO OTHER THAN AUTO ONLY: $$5,000,000 EACH OCCURRENCE AGGREGATE $ $5,000,000 WC STATU- OTH- TORY LIMITS i ER E.L. EACH ACCIDENT E.L. DISEASE - EA EMPLOYEE E.L. DISEASE - POLICY LIMIT LIMIT EACH LOSS $1,000,000 LIMIT AGGREGATE $1,0oo,ooo DEDUCTIBLE $ 10,0o0 CITY OF ASHLAND IS ADDITIONAL INSURED AS RESPECTS WORK PERFORMED CERTIFICATE HOLDER X ADDITIONAL INSURED; INSURER LETTER: A CANCELLATION CITY OF ASHLAND 20 E MAIN ST ASHLAND OR 97520- I ATTN: ENGINEERING ACORD 25-S (7/97) SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATIOI~ DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE [.EFT, BUT FAILURE TO DO SO SHALL IMPOSE NO OBLIGATION OR LIABILITY~ANY KIND UPON THE INSURER, ITS AGENTS OR /// AUT. OR,Z EPR E/? Certificate of Insurance THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE 14OLDER. THIS CERTIFICATE IS NOT AN INSURANCE POLICY ANI:) DOES NOT AMEND, EXTEND, OR ALTER THE COVERAGE AFFORDED BY THE POLICIES LISTED. This is to Certify that ROSS BROS. & COMPANY° INC. 3501 BROOKLAKE RD NE SALEM OR 97303-9712 I1,1,,I,,,I,,11,11,,,,,11,1,1,,I,,,I,,,11,,I,II1,,,,,,111,,I,I iLiberty iNorth%est. Member of Liberty Mutual Group P 0 Box 4555 Portland, OR 97208-4555 503.239.5800 is, at the date of the certificate, insured by the Company under the policy(les) listed below. The insurance afforded by 'the listed policy(les) is subject to all their terms, exclusions and conditions and is not altered by any requirement, term or condition of any contract or other document with respect to which this certiificate may be issued. EXPIRATION TYPE OF POLICY DATE POLICY NUMBER LIMITS OF LIABILITY COVERAGE AFFORDED UNDER W.C. LAW OF F. OVERAGE AFFORDED UNDER W.C. LAW OF FOLLOWING STATES: FOLLOWING STATES: ~ WORKERS' OR COMPENSATION 10 ! 01 ! 2004 WC4-1NC-O 11542 EMPLOYERS LIABILITY LIMITS EMPLOYERS LIABILII'Y LIMITS Each Accident $ 5 O0 , O00 Each Accident Disease - policy limit $ 500 ,000 Disease - policy limit Disease - each employee $ 5 O0 f 000 Disease - each employee S MARITIME COVERAGE-FOLLOWiNG STATES LIMIT OF LIAB.-MARITIME COVERAGE GENERAL LIABILITY General Aggregate $ [] Commercial General Products Comp/OPS Aggregate $ Liability (Occurrence) Personal & Advertising Injury $ r-] Owner, s and Each Occurrence $ Contractor's Protective Fire Damage (Any one fire) $ [] Medical Expense {Any one person) $ AUTOMOBILE LIABILITY [] Any Auto CSL $ [] All owned Autos Bodily Injury {Per Person) $ [] Scheduled Autos Bodily Injury {Per Accident) S [] Hired Autos Property Damage $ [] Non-owned Autos [] Garage Liability OTHER LOCATION{S) OF OPERATIONS & JOB t (IF APPLICABLE)' ' DESCRIPTION OF OPERATIONS WATER STREET BRIDGE RECONSTRUCTION PROJ NO. 2001-12-NOTICE OF AWARD SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING CANCELLATION: COMPANY WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED BELOW, BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE COMPANY, OR REPRESENTATIVES. MAILED To:CITY OF ASHLAND ENGINEERING ATTN: PAULA C BROWN 2O E MAIN ST ASHLAND OR 97520-1850 I1,1,,I,,,I,1,1,,,I,II1,,,,,,111,,I,,I,1,11,,,I,1,,I,1,,,I,1,1 CERTIFA EFS jh 7/13/2004 SALEM Marketing DATE ISSUED OFFICE CITY OF ASHLAND 20 E MAIN ST. ASHLAND, OR 97520 (541 ) 488-5300 O0FID R'S COPY DATE 8/2/2004 Page 1 / 1 I '.'. 'PO. NUMBER.. 05295 VENDOR: 008852 ROSS BROTHEP, S & COMPANY INC 3501 BROOKLAKE ROAD NE SALEM, OR 97303-9712 SHIP TO: Ashland Public Works (541 ) 488-5587 51 WINBURN WAY ASHLAND, OR 97520 FOB Point: Terms: Net Req. Del. Date: 7/27/2004 Special Inst: Req. No.: Dept.: PUBLIC WORKS Contact: Paula Brown Confirming? No BLANKET PURCHASE ORDER · .'.::.i'.:':':...:.:...i.~.:.::'.:.:" .:.:: :' ~.'. ':: '? '.. ~ : :.~'C0:hs:trb'cti~in.:.Wbrl~fbr::the:Water:Street:.'. ':.'.: ......... '...: :.:':.::. :..........:/:.......::.' .... . .. .:: ...~..:... ..:'.:'.:575, t'00:00. . Bridge reconstr~ucti0n project. Pr~oject '... ::...:. '.::i: .'.i.i~' ::.:~ .:: ':... :' '::.:.;.:' .": '".01:.~:12' .:.:'.:'..'~ :.' ":.i':.:. :'.':: .'"" "::"::':?. .":i :.'.::: " ::'." '""'.: "' :.: :.':.:"::::'.':"' '.'" ..'...' ..... "' ..'. :.'.' '.:.' BiD Start date: July 27, 2004 Completion date: Summer 2005 Insurance required / On file :: : SUBTOTAL 575,100.00 BILL TO: Account Payable TAX 0.00 20 EAST MAIN ST FREIGHT 0.00 541-552-2028 TOTAL 575,100.00 ASHLAND, OR 97520 Account Number Amount Account Number Amount E 260.08.12.00.704200 299,000.00 E 260.08.34.00.704200 186,400.00 E 670.08.18.00.704200 21,000.00 E 675.08.17.00.704200 68,700.00 VENDOR COPY REQUISITION CiTY OF -ASHLAND No. PW - FY 2005 Department Public Works Vendor ROSS BROTHER CO., INC. 3501 BROOKLAKE RD NE SALEM OR 97303-9712 Account No. SEE BELOW Date July 27, 2004 Requested Delivery Date ASAP Deliver To PAULA BROWN Via (* Note: Please allow approximately two(2) weeks for delivery on items not generally caried in stored, and approximately two (2) months on printing jobs.) Item No. Quantity Unit Description Use of Purchasing Office Only Unit Price Total Price PO No. Construction work for the Water Street Bridge reconstruction project. Accounts: 260.08.12.00.00.704200 $ 299,000.00 ~,~-"~c~.~ ~.,~, ........ 260.08.,1~.34.00.704200 $ 186,400.00 · ,,ti tt.z ' 670.08.18.00.00.704200 $ 21,000.00 ,,~ ~ ~- 675.08.17.00.00.704200 (collection portion) $ 58,200.00 L,~ ,, / 675.08.17.00.00.704200 (SDC Related) $ 10,500.00 7 ,,oo.oo for Kari: BID /RFP / EXEMPT: Bid Contract Start Date: July 27, 2004 Contract Completion Date: Summer 2005 InsUrance on file: I YES I NO Project No: 01-12 Job No. Unit No. I hereby certify that the above items are necessary for the operation of this department and are budgeted ~.s J ~ead or Authorized Person Issued By Date Received By This will be a multi-year project FY05 Y 06, there will be $299,000 STP/ODOT revenue. ~::~'~ G:Pub-wrkslengldept-adminlengineerlprojectJ01-12 Ross Bros Req 7 04