HomeMy WebLinkAbout1998-166 Contract - AndroitCITY OF ASHLAND
CONTRACT FOR PUBLIC WORKS CONSTRUCTION
Contract made this 23rd day of December, 1998, between the City of Ashland, ("City") and
Adroit Construction Co. Inc. ("Contractor").
City and Contractor agree:
Contract Documents: This contract is made as a result of an Advertisement of Bid issued by City
for the Crowson Reservoir Roof Replacement Project No. 96-12. Contractor was awarded the bid
as the lowest responsible bidder. In the event of any inconsistencies in the terms of this contract,
the contract documents defined in the Advertisement for Bid and Contractor's bid, this contract
shall take precedence over the contract documents which shall take precedence over the bid.
Scope: Contractor shall begin and complete the project described in the contract documents within
the time prescribed in the contract documents. The following exceptions, alterations, or
modifications to the contract documents are incorporated into this contract.
Price and Payment: City shall pay Contractor amounts earned under the contract. All payments
will be made at the times and in the manner provided in the contract documents.
Bond: Contractor shall, within five days after execution of the contract and prior to doing any work
under the contract, furnish bond to the City of Ashland in a form and with a surety satisfactory to
City in the penal sum of $ 399,600.00 conditioned upon the faithful performance of this contract
upon the part of the Contractor.
5. Default: A default shall occur under any of the following circumstances:
5.1
5.2
5.3
If the Contractor fails to begin the work under the contract within the time specified, or
fails to perform the work with sufficient workers or equipment or with sufficient materials
to insure the prompt completion of the project, or shall neglect or refuse to remove
materials or perform anew such work as shall be rejected as defective or unsuitable, or
shall discontinue the prosecution of the work.
If the Contractor shall become insolvent or declared bankrupt, or commit any act of
bankruptcy or insolvency, or allow any final judgment to stand against the Contractor
unsatisfied for a period of forty-eight hours, or shall make an assignment of the benefit of
creditors.
From any other cause whatsoever, shall not carry on the work in an unacceptable manner.
Remedies: In addition to the rights and remedies to which the City may be entitled by law for the
enforcement of its rights under this contract, City shall have full power and authority, without
violating this contract, to take the prosecution of the work from the Contractor, and appropriate
or use any or all of the materials and equipment on the ground that may be suitable and acceptable
and may cause a contract for the completion of this contract according to its terms and provisions,
G :Dawn',Engineer\Projecf',96-12 Contract Award Ltr.wpd
or use such methods as required for the completion of the contract, in any acceptable manner. All
costs and charges incurred by the City together with the costs of completing the work under the
contract, shall be deducted from any money due or which shall become due the Contractor. In case
the expense so incurred by the City shall be less than the sum which would have been payable
under the contract if it had been completed by the Contractor, then the Contractor shall be entitled
to received the difference less any damages for delay to which the City may be entitled. In case
such expense shall exceed the sum which would have been payable under the contract, the
Contractor and the surety shall be liable and agree to and shall pay the City the amount of the
excess with damages for delay of performance, if any.
Prevailing Wage Rates: The Contractor shall pay a fee equal to one-tenth of one percent (0.1%)
of the price of the price of this Contract. The fee shall be paid on or before the first progress
payment or 60 days from the date work first begins on the Contract, whichever comes first. The
tee is payable to Bureau of Labor and Industries and shall be mailed or otherwise delivered to the
Bureau at the following address:
Bureau of Labor and Industries
Wage and Hour Division
Prevailing Wage Unit
800 N.E. Oregon Street #32
Portland OR 97232
The Contractor shall fully comply with the provisions of ORS 279.348 through 279.365 pertaining
to prevailing wage rates.
CONTRACTOR
BY: Adroit Construction Co. ,Inc.
.It s: Rober t..,Mayers
CITY OF ASHLAND
BY: ~~"-~
Mike Freeman
City Administrator
Its: Vi~e-President .
REVIEWED AS TO FORM:
BY:
City Attorney
Date:
REVIEWED AS TO CONTENT:
BY:a entj~~Head --
Dep Date:
Coding:
(for City use only)
G:l)awn',Engineer',,Project",96-12 Contract Award Ltr.wpd
ACORD. CERTIFICATE OF
PRODUCER
Security Insurance Agency, Inc
1175 East Main St.
Medford OR 97504
Barbara J. Pinkham
Phone No 541-772-1111 F~x No.
iNSURED
/Adroit Construction Co., Inc.
'~ '/ P.O. Box 609
Ashland OR 97520
LIABILITY cs.,,.: :::: DATE M O
INSURANCEADROI- :
12/22/98
THIS CERTIFICATE IS ISSUED AS A MA'~'ER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
COMPANIES AFFORDING COVERAGE
COMPANY
A
COMPANY
B
COMPANY
C
COMPANY
D
North Pacific Insurance Co.
COVERAGES
CO
LTR
A
THIS IS TO CERTIFY THAT THE POUCIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD
INDICATED, NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,
EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
POLICY EFFECTIVE POLICY EXPIRATION
TYPE OF INSURANCE POLICY NUMBER DATE (MI'.VDD/YY) DATE (MM/DD/YY)
GENERAL LIAI~ILJTY
X COMMERCIALGENERALLIABILR~I' C08 10-55-02 01/01/98 01/01/99
:X J CLAIMS MADE ~--] OCCUR
AUTOMOBILE LIABILITY
A XIAr.~¥AuTo C08 10-55-02 01/01/98 01/01/99
AL~- OWNED AUTOS
SCHEDULED AUTOS
HtRED AUTOS
NON-OWNED AUTOS
LIMITS
GENERAL AGGREGATE $ 2,000,000
PRODUCTS- COMP/OP AGG $ 2 · 000 ~ 000
PERSONAL & ADV INJURY $ I r 000 · 000
EACH OCCURRENCE $1,000,000
FIRE DAMAGE (Any one fire) $ 50 ~ 000
MED EXP (Any one pemon) $ 5 t 000
COMBINED SINGLE LIMIT $ 1~000 ~000
BODILY INJURY $
(Per person)
BODILY INJURY $
(Per accident)
PROPERTY DAMAGE
GARAGE LIABILITY'
ANY AUTO
EXCESS LIABILITY
A X UMBRELLA FORM ECL12743 01/01/98 01/01/99
OTHER THAN UMBRELLA FORM
WORKERS COMPENSATION AND
EMPLOYERS' LIABILITY
THE PROPRIE~I'O~J ~ INC1_
PAR'R~ER~ED(ECUTIVE
OFFICERS ARE: EXCL
OTHER
AUTO ONLY - EA ACCIDENT
OTHER THAN AUTO ONLY:
EACH ACCIDENT
AGGREGATE
EACH OCCURRENCE S $5 r 000 ~ 000
AGGREGATE $ $ 5 , 000 ~ 000
$
WC STATU-
TORY L MITS I IOET~- i:::[:! ::::::::
EL EACH ACCIDENT $
EL DISEASE - POLICY LIMIT $
EL DISEASE - EA EMPLOYEE $
DESCRIPTION OF OPERATIONSA.OCATIONS/VEHICLES/SPECIAL ITEMS
Re: Crowson Reservoir Roof Repla?ement -. ~Pro~ec.t. No. _9..6-12. It .is hereby
understood and agreed that the Ci=y of Asn~an~, ~=s ozzlcers, _em_p-oyees are
added as additional insureds with respects the above project. Insurance
carried by the insured under this con%fact shall be primary coverage· and
.the City's insurance is excess.
CERTIFICATE HOLDER : : :: : : :: ::i:..:::' :.: i i :::::::::::::::::::::::::::::::::::::::::::::::::::::::
1AAAAAA SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE
ACORD25-S(1~5)
City of Ashland
Department of Public Works
20 East Main
Ashland OR 97520
Bond No. 2351 47 046023
PERFORMANCE AND PAYMENT BOND
The undersigned ADROIT CONSTRUCT[ON CO., INC.
· as principal, further referred to in this bond as Contractor, and EFq~LOYERS INSURANCE OF WAUSAU A ~tual
Ccm~ny , as surety, further referred to in this bond as Surety, are jointly and severally bound unto
City of Ashland, as obligee, fiather referred to in this bond as City, in the sum of * Dollars ($ 399,600.
)_ * Three Hundred Ninety Nine Thousand Six Hundred and No/100
Contractor and City have ~ntered into a written contract dated December 23, 1998 for t h e
following project: Crowson Keservoir Roof Replacement Project. This contract is further referred to in
this bond the Contract and is incorporated into this bond by this reference.
The conditions of iNs bond are:
If Contractor faithfixlly performs the Contract within the time pr~cribed by the Contract,
and promptly makes payment to all claimants, as defined in ORS 279.526 through 279.542,
then this obligation is null and void; otherwise it shall remain in full force and effect.
If Contractor is declared by City to be in default under the Contract, the Surety shall
promptly remedy the default, perform all of Contractor's obligations under the Contract
in accordance with its terms and conditions and pay to City all damages that axe due under
the Contract.
3. This bond is subject to claims under ORS 279.526 through 279.542.
This obligation joimiy and severally binds Contractor and Surety and their respective heirs,
executor, administrators, successors.
5. Surety waives notice of modifications of the Contract or extension of the Contract time.
6. Nonpayment of the bond premium shall not invalidate this bond.
O:Daw~agim~,~Projec~x96-12 Co~'.~ Awed Ltt. wl~l
The bond number and the name, address, and telephone number of the agent authorized to
receive notices concerning this bond aro as follows:
Bond Number 2351 47 046023
BondAgent Sedgwick of Oregon, Inc.
Address 111 SW Columbia
Portland, OR 97201-5897
Telephone
503/248-6400
SIGNeD this 22nd day of December .1998.
WITNESS:
(con~rm s~
Con,n-act~ ADROIT CONSTRUC. IION CO., INC.
By x
Rok~rt Maye~s
Title Vice-President
LegalAddress 693 Washinqton Street, Ashland, OR 97520
Attest
Sharon Smith_L~
Corporate $ecret~
Rot~r t Mayers '~'
Sur~ IMPtOY[RS NSUR~C~ ~,WAU$AU A MO%ual Company
Title Melissa C. Jones, Attorney-In-Fact
LegalAddress ?DO0 Westwood Drive/PO Box 8017
Wausau, WI 54402-8017
(_~xinette McWllliams as witness to Surety
Corporate Secretary N/A
'( I ~(~-~.'..~, (00S)'I'1¥9 'NISN()D~IAa Nit' 1991-9g~
dO HOh~Od SIH,L AO DNILIHOA~ Ha A£1(II'!VA 'AH£ DNi(IllVD~4H
'ualll!Jta aaoqe lsJI. J u!aJaq Jea,( pug ,(ep aq! leas le!oUjO `(tu pax!jje pug pueq Am
·.=atuo :r'4!! ~:1 olar~4l atueu s.al pa~.ts aq ~q~ pug uo!~e.mcboo p.ms jo ~crma~.R3 jop. mo~l atll jo Joppa `(q PaxUje
os set. 1! lmll pug l~aS ;ae~odmo qons s! lUatun.astq. p.ms o3 paxuje Feas all leql '.uo.u~oduo3 p.ms jo pros ~ st*ou'4 aq ~ .'ouaturmsu! aaoqe ap pa~noaxa
qo!qt. pug u! paq.uosap uo!~todaoo aq~ ',(tmdmoDlemnDl ¥ fI¥SflVA~ :IO ~tD~SNI SII~LCVId]~13 aql jo $uap!s~d a:)~ e s! aq nng3 ,(es pug
asodap p!p 'motas ,(!nP am g;q ~u.taq oqta 'utaomI am o1' tmX~[ uaqdas 'f
aum3 `(11t'uosaad am a~ojaq ' ~--"~'61 ' -~]s]. jo ~(ep q3 (~'[ s!ql uO
( NOH,L¥ll¥1~I AO AJ. NflOD
'ss
( NISNOD$1.9..40 2I,L¥,LS
- :lsall V
lu~p!s~l ~O!A tm.(1t uaqdals 'f
`(uedmoD lenln~ ¥ fl¥Sfl¥~ :i0 32)NY~!flSNI S~13AOqdlalkl
jo `(~p ~ q:3~l Slq~ PaXLU· olmaq aq ol [gas amao~boo s1! pu~ '/dela~as luels!sse sl! `(q palsaae ptm luap!smd ao!^ aql aq pau~!s
aq o~ sluasaad asaql pasha;)seq AuedmoD lenlnlN V iIVSf]VPA .40 3DNVafl,qNI Sll:4AO'Idl~I:4 '.40:4H:4 HA~ SS:4 N£1/~
,.*paqaelle s!
1oadsaa qa,!a~ aanlnj aql u! pug paxuje as uaqm AugdrooL) lemnl~l V f'IVSIqVM SO [4DNVllfISN1 SllHAO'hilN:4 aql uodn
~lu!pu!q pug Pile^ aq Heqs leas al!m!sae$ pug sa.inleu~!s
pug 'al!m!saej ,~q ooaaaql 31u!lelaa aleo!j!l.iao Aug o3 .lo Aau.~olle jo .lataod qans Aug ol paxuJe aq .(am ,~uedmo,D luninl&l V
51¥$flYA~ AO ~lDN¥llflSNl SltL4 AO'ldla/.51Jo leas aql pug s/ao!jjo qansjo saanleu~!s
,.'Auedm°D lenln16/ V fl¥SflYA~ dO 5IDi'qYHflSNI SllL4AO'IdlA/[.! jo leas aql Olaaaql
qoe:lle ol pug 'Kauaolle jo .~aaxod q;)ns Aug Jo uo!lnoaxa aql 1salle ol paz!aoqlne 's! Aqaaaq maql jo Kue .lo qoue lt:ql puu
'aq Kaelaa;)as luels!sse ao AaeOa.~aas Aug leql pug :d!qsAlaans.1o sl~e.zluoo iie pug sl~u!~el.iapun 'spuoq/~uedmo,) [enln[61
V flVSflYM .40 ~oqNV'llflSNl ~1t~lAOqctlfil.~I JO Jleqaq uo aln;)axa o3 Aau-olle jo
.~u!AJ!lenb .(au-o~le jo saataod aln~axa ol paz!aoqlne 's! Aqaaaq
SO 3DNVltflSNI SH,';IAOqdi6151 jo -- a^!lU!Odde ao a^!laala -- luap!sa.zd a~!A Aug pug luap!sa.zd aql leql '(l,'4A'IOS[tlt,,
:l~ajja u! II!ls s! uo!!nlosaa qo!qaa 'l:L61 'Ael~l JO Aep qlWI aql uo plaq pug pal[gO Alnp ~u!laam
ele AugdreaD p!esjo s.ioloa,q(l jo paeo[t aql Aq pa~dope uo!lnlosa.z :,lu!aaOl[OJ
-sas~ma.ld aql u! op Kern 1oej-u!-.KaUJOlD?
p!es aql leql IIe Zlu!maUuo;:) pug Zlu!A.:iDea Aqaaaq Aaelaaoas
ql!ax paleas 'luap!saad aql ,~q pauZl!s aaaax spuoq q~nsj! se lua~xa ames aql ol pug Aunj sg Aqaaaql uo!leaodao,) aq~ pu!q "1 puc
~' (000'000'0~$)
sav~qoa :qoz'rzz]g X,T4qO_~.T. a0 ~-qS q'V~.qa
3H.I O.L S%IOAIVM (INV X.I3%IflS .40 S.LNOSNOD DNI(h'I~iDNI .4031tOH£Oll;l£VN 3H.LNI SNOI,LVDI'iHO
NO,kLIH~ H3H,LO HO SODNVZINDO2)31J 'SDNI~I¥,LI:[3(INf] '$(INO8 qqv llO XNV aa^!lap pug al~palt*OU~lOe 'iv. as
'a~noaxa ol 'peals pug aoeld 'ameu s1! u! pal.zajuoo Xqaaaq Xl!.loqlne pug ,~at*od ilnj
NI.tgflv
'S~NOf 'D VSSI'I3~ 'SKWIqlI~i O~ 'q 3.T-I.qNVf 'NNX%4 'V XDV.T.S
lu!odde pue alm!~suoo 'a~em sluasa~d asaql Kq saop pue 'pa~u!odd~ pue palnlDsuoo 'apem seq 'u!suo~st~A
jo a~el$ 'uoqleae!~ jo ,{luno2) 'nesneA% 3o KI!D aql u!
aapun 8u!ls!xa pug pez!ue31ao Kinp uo!leaod.zoo e 'Auedmo
:S£NOgOlld 3S3H£ A~t NOI~ q'lV ~AON~
A3NHO,L,LV .40 H3~Od
UeOLUOO len nn V FI d'IVNt :10 NV !CF3NI
6 Z 0 0 0 'ON
CITY OF ASHLAND
C
ITY HALL
ASHLAND, OREGON 97520
TO:
NOTICE OF TRANSMITTAL
4~'ARBARA CHRISTENSEN
JILL TURNER
SHARLENE STEPHENS
DATE:
PROJECT:
JOB NO.:
SUBJECT:
DECEMBER 24, 1998
96-12
CROWSON RESERVOIR ROOF
REPAIR CONTRACT DOCUMENTS
THE FOLLOWING ITEMS ARE BEING SENT TO YOU:
Barbara - One duplicate original of the Crowson Reservoir Roof Repair Contract for your files.
Jill - Copy of the Contract and Performance Bond
Sharlene - Original of Certificate of Liability Insurance.
ENCLOSED ~ UNDER SEPARATE COVER
REMARKS:
COPIES TO:
Department of Public Works
Engineering Department
By: Jim Olson
Title: Engineering Services Manager
G: Dawn\Engineer\Project\96~96-12 Contract & PB to Records NOT.wpd