HomeMy WebLinkAbout1996-149 Contract - Headwaters
DEPARTMENT OF PUBLIC WORKS
ADMINISTRATION: (541) 488-5587
ENGINEERING: (541) 488-5347
4ude:r
CITY OF ASHLAND
C I T Y
HAL L
20 E. MAIN STREET
ASHLAND, OREGON 97520-1814
FAX (541)488-6006
September 9, 1996
COpy
Headwaters
Pam Tennity, Project Leader
P.O. Box 729
Ashland, OR 97520
Dear Pam:
Enclosed is the revised personal services contract for the Roca
Canyon Nonpoint Source Pollution Abatement Project. It needs to
be signed and returned to me, and I will see that it is
completed. I will forward a copy of the completed agreement to
you. Please be aware that, in addition to submitting the
quarterly reports, you will need to bill us in order to be paid
for the time periods indicated in the agreement.
Pursuant to paragraph 11 of the agreement dated July 1, 1996,
between the City of Ashland and Headwaters, the city consents to
the subcontracting for Linda Chesney, Steve Koskella, and Kerry
KenCairn.
If you have any questions, please call me at 488-5587.
~relY,
~~~ /~
Pamela J. Barlow~~
Administrative Assistant
Public Works Department
cc: Susan Wilson Broadus, P.E., Dir. Public Works
Paul Nolte, city Attorney
CITY OF ASHLAND PERSONAL SERVICES CONTRACT FOR SERVICES LESS THAN $15,000
1\ CITY OF ASHLAND, (CITY) CONSULTANT: Headwaters, c/o Pam Tennity
'I 20 E. Main St. Address: P.O, Box 729
I Ashland, Oregon 97520 Ashland, OR 97520
(503) 482-3211 FAX: (503) 488-5311 Telephone: (541) 482-4459 FAX: (541) 482-7282
AGREEMENT DATE: July 1, 1996 1:3. BEGINNING DATE: July 1,1996
!4, COMPENSATION: For services !3. COMPLETION DATE: Sept.1, 1997
rendered, not to $10,000
'11. SERVICES TO BE PROVIDED: Nonpoint Source Pollution Abatement Project as per attachement (monitoring,
site evaluation, project design); project implemented in coordination with DEQ 2-year funding of same project (to
implement project construction).
ADDITIONAL TERMS: To be paid as follows--
For initial assessment, payment on Oct. 1, 1996 .. ... . .. . . . .. . . . . . . . .. . . . . . . . .. ... . . . .. . .. . $2,500
Winter Quarter '97, Progress Report, Jan 1, 1997 . . . , , . . , , . . , , . . . . , . . , . . . . . , . . , . . . . . , , . , . . . . $2,500
Spring Quarter '97, Progress Report, Apr, 1, 1997 .. . .. . ... . . .. .. . . . . . .. . . . .. . . . .. . . . .. . .. . . $2,500
Final Report on City funded portion of project, Project Tour, Sept.1, 1997 . . . . . . , . . . . . . . . . . :. . . . . . . $2,500
CITY AND CONSULTANT AGREE:
1. All Costs bv Consultant: Consultant shall, at its own risk and expense, perform the personal services described above and, unless otherwise
specified, furnish all labor, equipment and materials required for the proper performance of such service.
2. Qualified Work: Consultant has represented, and by entering into this contract now represents, that all personnel assigned to the work
required under this contract are fully qualified to perform the service to which they will be assigned in a skilled and workerlike manner and, if
required to be registered, licensed or bonded by the State of Oregon, are so registered, licensed and bonded. Consultant shall also procure and
maintain a current City of Ashland business license.
3. Completion Date: Consuttant shall start performing the service under this contract by the date indicated above and complete the service by
the completion date indicated above.
4. Compensation: City shall pay Consultant for service performed, including costs and expenses, the sum of specified above. Once work
commences, Invoices shall be prepared and submitted by the tenth of the month for work completed in the prior month, Payments shall be
made within 30 days of the date of the invoice. Should the contract be prematurely terminated payments will be made for work completed and
accepted to date of termination.
5. Ownership of Documents: All documents prepared by Consultant pursuant to this contract shall be the property of City.
6. Statutorv ReQuirements: OAS 279.312,279.314,279.316 and 279.320 are made part of this contract.
7. Indemnification: Consultant agrees to defend, indemnify and save City, its officers, employees and agents harmless from any and all losses,
claims, actions, costs, expenses, judgments, subrogations, or other damages resulting from injury to any person Qncluding injury resulting in
death,) or damage (including loss or destruction) to property, of whatsoever nature arising out of or incident to the performance of this contract
by Consultant Qncluding but not limited to, Consultant's employees, agents, and others designated by Consuttant to perform work or services
attendant to this contract.) Consultant shall not be held responsible for any losses, expenses, claims, subrogations, actions, costs, judgments, or
other damages, directly, solely, and approximately caused by the negligence of City.
8. Termination: This contract may be terminated by City by giving ten days written notice to Consultant and may be terminated by Consultant
should City fail substantially to perform its obligations through no fault of Consultant.
9. Independent Contractor Status: Consultant is an independent contractor and not an employee of the City. Consultant shall have the
complete responsibility for the performance of this contract. Consultant shall provide workers' compensation coverage as required in OAS Ch
656 for all persons employed to perform work pursuant to this contract and prior to commencing any work, Consultant shall provide City with
adequate proof of workers' compensation coverage. Consultant is a subject employer that will comply with ORS 656.017.
10. Insurance: Consultant shall, at its own expense, at all times during the term of this agreement, maintain in force a comprehensive general
liability policy including coverage for contractual liability for obligations assumed under this Contract, blanket contractual liability, professional
errors and omissions, products and completed operations and comprehensive automobile liability including owned and non-owned automobiles.
The liability under each policy shall be a minimum of $500,000 per occurrence (combined single limit for bodily injury and property damage
claims) or $500,000 per occurrence for bodily injury and $100,000 per occurrence for property damage. Uability coverage shall be provided on
an "occurrence" not "claims" basis. The City of Ashland, its officers, employees and agents shall be named as additional insureds. Certificates
of insurance acceptable to the City shall be filed with City's Risk Manager prior to the commencement of any services by Consultant under this
agreement. These certificates shall contain provision that coverages afforded under the policies can not be canceled and restrictive
modifications cannot be made until at least 30 days prior written notice has been given to City. A certificate which states merely that the issuing
company "will endeavor to mail" written notice is unacceptable.
11. Assianment and Subcontracts: Consultant shall not assign this contract or subcontract any portion of the work without the written consent
of City. My attempted assignment or subcontract without written consent of City shall be void. Consultant shall be fully responsible for the acts
or omissions of any assigns or subcontractors and of all persons employed by them, and the approval by City of any assignment or subcontract
shall not create any contractual relation between the assignee or subcontractor and City.
CONSULTANT:
CITY OF ASHLAND:
BY
Director of Finance
CONTENT REVIEW:
FORM REVIEW:
Purchase Order #
Coding:
(City Dept. Head) Date:
(City Attorney) Date:
BY
Its
Fed. 10 #
(for City purposes only)
CITY OF ASHlAND PERSONAL SERVICES CONTRACT <$15,000 (p:forms \ Hhrtps.fk)(rev'd 7 j93)(G:\Pam \ roes J'SC.frm-pg.2)
.te: 9-Sep-96 11:56
. L',Jm: SHARLENE@fs1 (Sharlene Stephens Attorney)
<;: PAM
;ubject: Revised PSC for Headwaters' Roca Storm Water Project
Message-id: D6053432015F3179
Pam: You sent Paul a message last week stating that a letter has been
requested from the city regarding giving consent to assign contract duties to
subcontractors. Per Paul, your letter can simply read: "Pursuant to paragraph
11 of the agreement dated July 1, 1996, between City of Ashland and Headwaters,
city consents to the subcontracting for Linda chesney, steve Koskella, and
Kerry KenCairn." --Sharlene