Loading...
HomeMy WebLinkAbout2021-144 PO 20220198- Pressure Point Roofing, Inc. Purchase Order VrPri/4Fiscal Year 2022 Page: 1 of: 1 `1T�AA S MBb B City of Ashland _ I ATTN: Accounts PayableL. 20 E. Main Purchase L Ashland, OR 97520 Order# 20220198 T Phone: 541/552-2010 O Email: payable@ashland.or.us ✓ H C/O Facilities Maintenance Div E PRESSURE POINT ROOFING INC I 90 North Mountain Ave N 5235 RAINBOW DR p Ashland, OR 97520 O CENTRAL POINT, OR 97502 Phone: 541/488-5358 RT Fax: 541/552-2304 (541) 772_-1945 -David Arnold $ ssr _._La e! 11/29/2021 997 FOB ASHLANDIOR City Accounts Payable _ Jterx = _ _ r -- __ ..._ HOLY a -�': }'��' ;may £ ' ;AV.-7y`�!�,,E, ''�g1 � �� V� �-� Repair Roof Hardesty Property 1 Repair roof at Hardesty Property 1.0 $4,320.00 $4,320.00 Goods and Services Agreement($35,000 or Less) Completion date: June 30,,2022 Project Account: *************** GL SUMMARY*************** 088400-602400 $4,320.00 • By: /flit- /,meg! Date: 6/" �- � Authorized Signatures = '.4 320.00 i i FORM #3 • CITY OF P � �, request for e P LIMII@S , Orc1P- 0 F-7 CP l fg REQUISITION Date of request: 10(8(2021. ' Required date for delivery: , Vendor Name Pressure Point Roofing.Inc. • Address,City,State,Zip 5235 Rainbow Drive.Central Point.OR 97502 Contact Name&Telephone Number Greg Monroe 541-722-1945 Email address SOURCING METHOD ' • ❑ Exempt from Competitive Bidding ❑' Emergency ❑ Reason for exemption: 0 Invitation to Bid 0 Form#13,Written findings and Authorization ❑ AMC 2.50 Date approved by Council: 0 Written quote or proposal attached ❑ Written quote or proposal attached (Attach copy of council communication) I If council a.'royal re.uired,attach co. of CC ® Small Procurement 0 Request for Proposal Cooperative Procurement • Not exceeding$5,000 Date approved by Council: 0 State of Oregon ® Direct Award _(Attach copy of council communication) Contract# ❑ Verbal/Written quote(s)or proposal(s) 0 Request for Qualifications(Public Works) 0 State of Washington Date approved by Council: Contract# (Attach copy of council communication) I ❑ Other government agency contract Intermediate Procurement 0 Sole Source Agency GOODS&SERVICES 0 Applicable Form(#5,6,7 or 8) Contract# - Greater than$5,000 and less than$100,000 ❑ Written quote or proposal attached Intergovernmental Agreement ❑ (3)Written quotes and solicitation attached 0 Form#4,Personal Services>$5K&<$75K Agency PERSONAL SERVICES 0 Special Procurement 0 Annual cost to City does not exceed$25,000. Greater than$5,000 and less than$75,000 ❑ Form#9,Request for Approval Agreement approved by Legal and approved/signed by ❑ Direct appointment not to exceed$35,000 0 Written quote or proposal attached City Administrator.AMC 2.50.070(4) _ 0 (3)Written proposals/written solicitation " Date approved by Council: 0 Annual cost to City exceeds$25,000,Council ❑ Form#4,Personal Services>$5K&<$75K ' Valid until: (Date). approval required.(Attach copy of council communication) Description of SERVICES Total Cost Repair roof at Hardesty Property $02040 ' • . Item# Quantity Unit Description of MATERIALS Unit Price Total Cost • ❑ Per attached quote/proposal `TOTAL:COST Project Number _ _ _ Account Number 088400-602400 _ .- .. , _ *Expenditure must be charged to the appropriate account numbers for the financials to accurately reflect the actual expenditures. IT Director in collaboration with department to approve all hardware and software purchases: IT Director Date Support-Yes/No By signing this requisition form,I certify that the C 's put c contracting requirements have been satisf/ed. Employee: {� / Department r t ktkil � tt He. . . o or greater than$5,000) Department ManageriSupervisor: City Administrator: (Equal to or greater than$25,000) Funds appropriated for current fiscal year: YES /NO Deputy Finance Director-(Equal to or greater than$5,000) Date Comments: • Form#3-Requisition GOODS AND SERVICES AGREEMENT($35,000 OR LESS) PROVIDER: Pressure Point Roofing,Ina. CITY O F PROVIDER'S ' AS H LAN D CONTACT: Greg Monroe 20 East Main Street Ashland,Oregon 97520 ADDRESS: 5235 Rainbow Drive Telephone: 541/488-5587 Central Point,OR 97502 Fax: 541/488-6006 PHONE: 541-722-1945 This Goods and Services Agreement (hereinafter "Agreement") is entered into by and between,the City of Ashland, an Oregon municipal corporation. (hereinafter "City") and Pressure Point Roofing, Inc., (a domestic/foreign business corporation)("hereinafter"Provider"),for roof repair. 1. PROVIDER'S OBLIGATIONS ' • 1.1 Provide roof repair on Hardesty'Property as set forth iri the"SUPPORTING DOCUMENTS" attached hereto and,by this reference,incorporated herein. Provider expressly acknowledges that time is of the essence of any completion date set forth in the SUPPORTING DOCUMENTS,and that no waiver or extension of such deadline may be authorized except in the same manner as herein provided for authority to exceed the maximum compensation. The services defined and described in the "SUPPORTING DOCUMENTS"shall hereinafter be collectively referred to as"Work." . 1.2 Provider shall obtain and maintain during the term of this Agreement and until City's final acceptance of all Work received hereunder,a policy or policies of liability insurance including commercial general liability insurance with a combined single limit, or the equivalent, of riot less than $2,000,000 (two ' • million dollars)per occurrence for Bodily Injury and Property Damage. 1.2.1 The insurance required in this Article shall include the following coverages: • Comprehensive General or Commercial General Liability, including personal injury, contractual liability,and products/completed o erations coverage; and • Automobile Liability. 1.2.2 Each policy of such insurance shall be on an "occurrence"and not a"claims made" form, and shall: • Name as additional insured "the City of Ashland, Oregon, its officers, agents and �. employees" with respect to claims arising out of the provision of Work under this Agreement; it Apply to each named and additional named insured as though a separate policy had been issued to each,provided that the policy limits shall not be increased thereby; • Apply as primary coverage for each additional named insured except to the extent that two or more such policies are intended to "layer" coverage and,taken together, they provide total coverage fromrthe first dollar of liability; • Provider shall immediately.notify the City of any change in insurance coverage • Provider shall supply an endorsement naming the City;its officers,employees and agents as additional insureds by the Effective Date of this Agreement; and c Be evidenced by a certificate or certificates of such insurance approved by the City. Page 1 of 6: Goods and Services Agreement between the City of Ashland and Pressure Point Roofing,Inc. 1.3 Provider shall,at its own expense,maintain Worker's Compensation Insurance in compliance with ORS 656.017, which requires subject employers to provide wirkers' compensation coverage for all of its subject workers. 1.4 Provider agrees that no person shall, on the grounds of race, color, religion, creed, sex,marital status, familial status or domestic partnership, national origin, gage, mental or physical disability, sexual orientation, gender identity or source of income, suffer (discrimination in the performance of this Agreement when employed by Provider. Provider agrees to comply with all applicable requirements of federal and state civil rights and rehabilitation statutes, rules and regulations. Further, Provider agrees not to discriminate against a disadvantaged business enterprise,minority-owned business,woman-owned business, a business that a service-disabled veteran owns or an emerging small business enterprise certified under ORS 200.055,in awarding subcontracts as required by ORS 279A.110. 1.5 In all solicitations either by competitive bidding or negotiation made by Provider for work to be performed under a subcontract, including procurements of materials or leases of equipment, each potential subcontractor or supplier shall be notified by the Providers of the Provider's obligations under this Agreement and Title VI of the Civil Rights Act of 1964 and other federal nondiscrimination laws. 1.6 Living Wage Requirements: If the amount of this Agreement is $22,310.46;or more, Provider is required to comply with Chapter 3.12 of the Ashland Municipal Code by paying a living wage,as defined in that chapter, to all employees performing Work under this Agreement and to any'Subcontractor who performs 50% or more of the Work under this Agreement. Provider is also required to post the notice attached hereto as"Exhibit A"predominantly in areas where)it will be seen by all employees. 1.7 Assignment: Provider shall not assign this Agreement or subcontract any portion of the Work to be provided hereunder without the prior written consent of the City. Any attempted assignment or subcontract without written consent of the City shall be void. Provider shall be fully responsible for the acts or omissions of any assigns or subcontractors and of all persons employed by them,and the approval by the City of any assignment or subcontract shall not create any contractual relation between the assignee or subcontractor and the City. 2. CITY'S OBLIGATIONS 2.1 City shall pay Provider the hourly rates effective October 7, 2021 as specified in the SUPPORTING DOCUMENTS. 2.2 In no event shall Provider's total of all compensation and reimbursement under this Agreement exceed the sum of$4,320 (this is maximum,not to exceed amount of ENTIRE Agreement) without express, written approval from the City official whose signature appears below, or such official's successor in office. Provider expressly acknowledges that no other person has authority to order or authorize additional Work which would cause this maximum sum to be exceeded and that any authorization from the responsible official must be in writing. Provider furtherliacknowledges that any Work delivered or expenses incurred without authorization as provided herein is done at Provider's own risk and as a volunteer without expectation of compensation or reimbursement. 3. GENERAL PROVISIONS 3.1 This is a non-exclusive Agreement. City is not obligated to procure any specific amount of Work from Provider and is free to procure similar types of goods and services from other providers in its sole discretion. Page 2 of 6: Goods and Services Agreement between the City of Ashland and Pressure Point Roofing,Inc.-- 3.2 Provider is an independent contractor and not an employee or agent of the City for any purpose. 3.3 Provider is not entitled to,and expressly waives all claims to City benefits such as health and disability insurance,paid leave,and retirement. 3.4 This Agreement embodies the full and complete understanding of the parties respecting the subject matter hereof. It supersedes all prior agreements,negotiations,and representations between the parties, whether written or oral. 3.5 This Agreement may be amended only by written instrument executed with the same formalities as this Agreement. 3.6 The following laws of the State of Oregon are hereby incorporated by reference into this Agreement: ORS 279B.220,279B.230 and 279B.235. 3.7 This Agreement shall be governed by the laws of the State of Oregon without regard to conflict of laws principles. Exclusive venue for litigation of any action arising under this Agreement shall be in the Circuit Court of the State of Oregon for Jackson County unless exclusive jurisdiction is in federal court, in which case exclusive venue shall be in the federal district court for the district of Oregon. Each party expressly waives any and all rights to maintain an action under this Agreement in any other venue,and expressly consents that, upon motion of the other party, any case may be dismissed or its venue transferred,as appropriate,so as to effectuate this choice of venue. 3.8 Provider shall defend,save,hold harmless and indemnify the City and its officers,employees and agents from and against any and all claims, suits, actions, losses, damages,-liabilities, costs, and expenses of any,nature resulting from, arising out of, or relating to the activities of Provider or its officers; employees, contractors,or agents under this Agreement. - 3.9 Neither party to this Agreement shall hold the other responsible for damages or delay in performance caused by acts of God,strikes,lockouts,accidents,or other events beyond the control of the other or the other's officers,employees or agents. 3.10 If any provision of this Agreement is found by a court of competent jurisdiction to be unenforceable, such provision shall not affect the other provisions, but such unenforceable provision shall be deemed modified to the extent necessary to render it enforceable, preserving to the fullest extent permitted the intent of Provider and the City set forth in this Agreement. 3.11 Deliveries will be F.O.B destination.Provider shall pay all transportation and handling charges for the Goods.Provider is responsible and liable for loss or damage until fmal inspection and acceptance of the Goods by the City. Provider remains liable for latent defects, fraud, and warranties. 3.12 The City may inspect and test the Goods. The City may reject non-conforming Goods and require Provider to correct them without charge or deliver them at a reduced price, as negotiated. If Provider i3 does not cure any defects within a reasonable time, the City may reject the Goods and cancel this Agreement in whole or in part. This paragraph does not affect or limit the City's rights, including its rights under the Uniform Commercial Code,ORS Chapter 72(UCC). 3.13 Provider represents and warrants that the Goods are new, current, and fully warranted by the manufacturer. Delivered Goods will comply with SUPPORTING DOCUMENTS and be free from defects in labor,material and manufacture.Provider shall trnsfer all warranties to the City. Page 3 of 6: Goods and Services Agreement between the City of Ashland and Pressure Point Roofing,Inc. 4. SUPPORTING DOCUMENTS 4.1 The following documents are, by this reference, expressly incorporated in this Agreement, and are collectively referred to in this Agreement as the "SUPPORTING DOCUMENTS:" • The Provider's complete written Estimate dated October 7,2021. 4.2 This Agreement and the SUPPORTING DOCUMENTS shall be construed to be mutually complimentary and supplementary wherever possible. In the event of a conflict which cannot be so resolved,the provisions of this Agreement itself shall control over any conflicting provisions in any of the SUPPORTING DOCUMENTS. In the event of conflict between provisions of two of the SUPPORTING DOCUMENTS,the several supporting documents shall be given precedence in the order listed in Article 4.1. 5. REMEDIES 5.1 In the event Provider is in default of this Agreement, City may, at its option, pursue any or all of the remedies available to it under this Agreement and at law or in equity,including,but not limited to: 5.1.1 Termination of this Agreement; 5.1.2 Withholding all monies due for the Work that Provider has failed to deliver within any scheduled completion dates or any Work that have been delivered inadequately or defectively; 5.1.3 Initiation of an action or proceeding for damages, specific performance, or declaratory or injunctive relief; 5.1.4 These remedies are cumulative to the extent the remedies are not inconsistent,and City may pursue any remedy or remedies singly,collectively,successively or in any order whatsoever. 5.2 In no event shall City be liable to Provider for any expenses related to termination of this Agreement or for anticipated profits. If previous amounts paid to Provider exceed the amount due,Provider shall pay immediately any excess to City upon written demand provided. 6. TERM AND TERNIINATION 6.1 Term This Agreement shall be effective from the date of execution on behalf of the City as set forth below (the `Effective Date"), and shall continue in full force and effect until June 30, 2022, unless sooner terminated as provided in Subsection 6.2. 6.2 Termination 6.2.1 The City and Provider may terminate this Agreement by mutual agreement at any time. 6.2.2 The-City may,upon not less than thirty(30)days' prior written notice,terminate this Agreement for any reason deemed appropriate in its sole discretion. 6.2.3 Either party may terminate this Agreement,with cause by not less than fourteen (14)days' prior written notice if the cause is not cured within that fourteen (14) day period after written notice. Such termination is in addition to and not in lieu of any other remedy at law or equity. 7. NOTICE Whenever notice is required or permitted to be given under this Agreement, such notice shall be given in writing to the other party by personal delivery, by sending via a reputable commercial overnight courier, or by mailing using registered or certified United States mail, return receipt requested,postage prepaid, to the address set forth below: 1 If to the City: !� Page 4 of 6: Goods and Services Agreement between the City of Ashland and Pressure Point Roofing,Inc. City of Ashland—Facilities Maintenance Department • Attn: David Arnold • 20 E.Main Street Ashland,Oregon 97520 Phone: (541)552-2292 With a copy to: City of Ashland—Legal Department 20 E.Main Street Ashland,OR 97520 Phone:(541)488-5350 If to Provider: Pressure Point Roofing,Inc. Attn:Greg Monroe 541-722-1945 8. WAIVER OF BREACH One or more waivers or failures to object by either party to the other's breach of any provision,term,condition, or covenant contained in this Agreement shall not be construed as a waiver of any subsequent breach,whether or not of the same nature. 9. PROVIDER'S COMPLIANCE WITH TAX LAWS 9.1 Provider represents and warrants to the City that: 9.1.1 Provider shall, throughout the term of this Agreement, including any extensions hereof, comply with: (i) All tax laws of the State of Oregon, including but not limited to ORS 305.620 and ORS chapters 316,317,and 318; (ii) Any tax provisions imposed by a political subdivision of the State of Oregon applicable to Provider;and (iii) Any rules,regulations,charter provisions,or ordinances that implement or enforce any of the foregoing tax laws or provisions. 9.1.2 Provider, for a period of no fewer than six(6)calendar years preceding the Effective Date of this Agreement, has faithfully complied with: (i) All tax laws of the State of Oregon, including but not limited to ORS 305.620 and ORS chapters 316,317, and 318; (ii) Any tax provisions imposed by a political subdivision of the State of Oregon applicable to Provider;and (iii) Any rules,regulations,charter provisions,or ordinances that implement or enforce any of the foregoing tax laws or provisions. ' 9.2 Provider's failure to comply with the tax laws of the State of Oregon and all applicable tax laws of any political subdivision of the State of Oregon shall constitute a material breach of this Agreement. Further, any violation of Provider's warranty, as set forth in this Article 9, shall constitute a material breach of this Agreement. Any, material breach of this Agreement shall entitle the City to terminate this Agreement and to seek damages andany other relief available under this Agreement,at law,or in equity. . Page 5 of 6: Goods and Services Agreement between the City of Ashland and Pressure Point Roofing,Inc. IN WITNESS WHEREOF the parties have caused this Agreement to be signed in their respective names by their duly authorized representatives as of the dates set forth below. CITY OF ASHLAND: Pressure Point Roofing,Inc. (PROVIDER): BY: By:By: as) Y " re Weilieture &ASTI' FLE-URNi (? M o,1 re)-e _ Printed Name, P ni ted Name Pwa- - kt eee5 pl2 Tx �z Sa- n- 0. l Ca n S.,t aa,‘ Title Title LII,4'l21 8- Z Date Date (W-9 is to be submitted with this signed Agreement) Purchase Order No. �� / / e Page 6 of 6: Goods and Services Agreement between the City of Ashland and Pressure Point Roofing,Inc. PRESSURE-oiN'r. 10/07/2021 Pressure Point Roofing,Inc. Claim Information 5235 Rainbow Dr. Central Point,OR 97502 Phone:541-772-1945 Fax:541-664-1772 Company Representative Nick Metcalf Phone:(541)772-1945 • nickm@pressurepointroofing.com • David Arnold Job:20250:David Arnold City Of Ashland 1291 Oak Street Ashland,OR 97520 • (541)552-2292 Construction/Tile Roof • Remove enough tile to access the plywood on the soffit.Approximately 2Sq.*pet aside tile for reinstallation. Remove the battens,underlayment and plywood.We must replace full sheets of plywood to maintain the strength in the soffit overhang. Install new sheathing as needed,to match existing.Install sheathing with ring shank nails.Nail sheathing onto new barge rafter as well. Install new 2'x 6"primed,vintage,pine barge rafter and fasten to out riggers using structural screws. I i Install new 30Ib felt underlayment and tile battens. Reinstall tile that was set aside for reinstallation. Install gable tiles,to match existing as close as possible.*Gable tile used could be recycled depending on availability. Clean up any and all debris related to this project. I I **New barge rafter and sheathing will need to be painted.Pressure Point does not provide this service. $4,320.00 CCB#80247 Understructure,(if necessary)is additional at Time($95 per man hour)and Materials(plus 10%).We will notify owner if additional work is needed before proceeding.Payment terms:25%Down,Balance upon project completion.Payment to be made within 10 days receipt of invoice. By signing below,customer acknowledges receipt of State required notices(when applicable.) All checks should be payable to Pressure Point Roofing,Inc.A finance charge of 1.5%per month(18%per annum)will be assessed on all accounts past due. Credit cards will be charged a 3%users fee. WARRANTY AND RIGHT OF RESCISSION:Customer acknowledges that they understand the right of rescission and warranties set forth on the reverse side of this agreement.You,the buyer,may cancel this transaction at any time prior to midnight of the third business day after the date of this transaction.See the attached notice of cancellation form for an explanation of this right. • Disputes to be Arbitrated.Any dispute between the parties concerning the interpretation,application,enforcement or validity of this agreement shall be arbitrated under Chapter 13 of the Uniform Trial Court Rules effective August 1,1990 or as amended thereafter.All arbitration hearings shall take place in Jackson County,Oregon.The cost of arbitration shall be shared equally between the parties;however,the prevailing party shall be entitled to recover the attorney's fees incurred concerning the arbitration and/or any appeal thereof.In the event Owner or Contractor shall take any action,judicial or otherwise,concerning this agreement,including but not limited to enforcement or interpretation of any terms of the agreement,the prevailing party shall be entitled to recover from the other party all expenses which it may reasonably incur in taking such action,including but not limited to costs incurred in searching records,the cost of title reports,taking and transcribing of depositions,surveyor reports and foreclosure reports and attorney fees,whether incurred in a suit or action or appeal from a judgment or decree therein or in connection with non-judicial action,Including the giving by Contractor to Owner of any notice necessitated by Owner's failure to comply with any terms of this contract. LIMITED WARRANTY LIMITED WARRANTY PRESSURE POINT ROOFING WILL WARRANTY FOR 2 YEARS,THAT THE SERVICE PER ORMED BY PRESSURE POINT ROOFING WILL BE FREE FROM DEFECTS IN WORKMANSHIP. LABOR AND MATERIALS NECESSARY TO REPAIR ANY WORKMANSHIP PROBLEMS WILL BE SUPPLIED BY PRESSURE POINT ROOFING,INC.AT NO ADDITIONAL COST TO THE CUSTOMER. THIS WARRANTY IS TRANSFERABLE ONE TIME.THE TRANSFERRED WARRANTY IS VALID FOR A PERIOD OF 2 YEARS FROM THE DATE OF OWNERSHIP CHANGE(OR WHATEVER TIME IS REMAINING).TRANSFERRED WARRANTIES ARE HONORED ONLY IF PRESSURE POINT,INC.IS NOTIFIED(IN WRITING)WITHIN 30 DAYS OF THE PROPERTY SALE. • Limitations: This warranty does not cover damages caused by acts of God,such as fire,excessive wind trees,branches,or other heavy foreign objects falling on or through the roof system.Note:Wind damage limit is determined by the manufacturer's warranty coverage. This warranty does not cover damages caused by foot traffic,improper maintenance,lack of maintenance,negligence or abuse. • This warranty does not cover any defects in or failure of materials.Please refer to the manufacturer's warranty,where applicable,for terms and limitations on material warranties. This warranty does not cover damages resulting from leaks'or other causes. This warranty becomes null and void if any workmanship is performed on the project or any of its components other than that of Pressure Point Roofing,Inc. THIS WARRANTY IS IN EFFECT AS OF THE DATE OF COMPLETION AND ONCE INVOICE HAS BEEN PAID IN FULL. • Company Authorized Signature Date Customer Signature Date Customer Signature Date r ' • -------*Th co DATE(MIIDDNYYY) • A5 D • CERTIFICATE OF LIABILITY INSURANCE 12/o7/ao2o THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES j BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACTETWEEN THE ISSUING INSURER(S), AUTHORIZED i REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. �' IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED,the pollcy(fes)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s)1. I PRODUCER .CONTACT I NAME: Tom 1 Kalduneki S Hart Insurance Agency - Medford PHONE PO Box 1240 (AIC.No.EMI: (541') 779-4232 (AM.Nol : E-MAIL1 ADDRESS: II Grants Pave OR 97528 • 1 INSURER(S)AFFORDINGCOVERAGE NAICN - INSURERA:Mutuel of Enumclaw Insurance O 14761 i INSURED (541) 772-1945 INSURER B: Pressure Point Roofing Inc ' INSURER C: 5235 Rainbow Drive INSURER D: _ I ; Central Point OR 97502 INSURER El INSURER P: • COVERAGES CERTIFICATE NUMBER:Cert ID 17819 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS !. CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INS TYPE ADDLSUBR POUCY EFF POLICY EXP LIMITS LTR INSR WVD POLICY NUMBER (MMIDDNYYY)'(MM/DDNYYYI ) ; COMMERCIALGENERAL LIABILITY EACH OCCURRENCE $ PREM • CLAIMS-MADE I I OCCUR DAMAGE MISES(Ea occurrence) $ • MED EXP(Any one person) $ i PERSONAL&ADV INJURY $ GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ IPOLICY ri jEOT I 1 100 PRODUCTS-COMP/OP AGG $ OTHER: $ AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT (Ea accident) $ 1,000,000 A X ANYAUTO Y CPP0002914 12/06/2020 12/06/2021 BODILY INJURY(Per person) $ I OWNED `SCHEDULED AUTOS ONLY _ AUTOS BODILY INJURY(Per acddenl) $ 1 , HIRED NON-OWNED (Per accident) $ AUTOS ONLY AUTOS ONLY PROPERTY DAMAGE UMBRELLA LIAB _ OCCUR EACH OCCURRENCE $ EXCESS LIAR CLAIMS-MADE AGGREGATE $ DOD RETENTIONS $ , WOREMPLOYERS'LIABILITY STATUTE ER OTH- AND EMPLOYERS'LIABILITY YIN ANYPROPREETOWPARTNERIEXECUTIVE NIA E.L.EACH ACCIDENT . $ OFFICERIMEMBEREXCLUDED? (Mandatory in NH) . E.L.DISEASE-EA EMPLOYEE $ Ifppes descrtbeunder ' E.L.DISEASE-POLICY UMIT $ DESaRIPTION OF OPERATIONS below $ $ DESCRIPTION OF OPERATIONS ILOCATIONS/VEHICLES(ACORD 101,Additional Remarks schedule,may beattached ifm�Irespaceisrequlred) additional insureds The City of Ashland, Oregon, its officers, agents an employees with respect to claims arising out the of the provision of work under agreement form EA9911 attached and applies u I . CERTIFICATE HOLDER CANCELLATION P • ( SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. 1. City of Ashland I 1 90North Mountain Avenue AUUTTTHORIZEDREPRESENTATIVE Ashland OR 97520 t/ I I ( • ©11988-2010 ACORD CORPORATION. All rights reserved. r ACORD 25(2016103) The ACORD name and logo are registered marks of ACORD i n;.r... 1 ..P 1 ' ® bATE(MMIDDNYYY) AC fo • CERTIFICATE OF LIABILITY INSURANCE 10/01/2020 • THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE'A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED,the policy(les)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement, A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER comer Hart Xneuranae Agency - Medford NAME: Tom Kalduneki PO Box 1290 g Y (NC. Ex(); (541) 779-4232 FAX INC.Nob EMAIL Grants Past( OR 97520 ADDRESS: kdolmageOhartinsurance.00m INSURER(S)AFFORDING COVERAGE NAIL// INSURER A:SAXP Corporation 36196 INSURED INSURER B: Pressure Point Roofing Ina INSURER C: 5235 Rainbow Drive INSURER 0: Central Point OR 97502 INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER:Cart ID 17270 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED'NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY1PAID CLAIMS. INSR ADM SUER POLICY EFF I POLICY EXP LTR TYPE OF INSURANCE INSU WVb POLICY NUMBER IMMIDDNYYYI (MMIDDNYYYI LIMITS COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE S CLAIMS•MADE PI OCCUR / PREM SESO(Ea occurrence) $ MED EXP(Any one person) $ PERSONAL&ADV INJURY $ GEN'LAGGREGATE LIMITAPPLILIES �SPER: GENERALAGGREGATE POLICY I I JECT I( 110C PRODUCTS-COMP/OP AGG S OTHER: AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ (Ea accident) ANY AUTO i BODILY INJURY(Per person) $• OWNED SCHEDULED BODILY INJURY(Per scolded) $ AUTOS ONLY _.- AUTOS HIRED NON-OWNED PPReOERTYAMAGE $ AUTOS ONLY AUTOS ONLY _ $ UMBRELLA LIAB OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DEO RETENTION S $ WORKERS LAXSR E "RANDEMPLOYERS'LIABILITY Y/N 945959 10/01/2020 10/01/2021 TATUTE ANYPROPRIETORIPARTNERIEXECUTIVE E.LEACH ACCIDENT $ 1,000,000- OFFICERIMEMBEREXCLUOED7 NIA (Mandatory lnNH1 E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ 1,000,000 $ $ DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be atlached If more space is required) i { CERTIFICATE HOLDER CANCELLATION . SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. City of Ashland 90 North Mountain Avenue A,,UTTHORIZEDREPRE EEN�TTCATIVE . Aehiand OR 97520 /iu i ©1988-2018 ACORD CORPORATION. All rights reserved, ACORD 26(2016103) The ACORD name and logo are registered marks of ACORD • • DATE(MMIDDIYYYY) -A�D® CERTIFICATE OF LIABILITY INSURANCE 03/25/2021 • THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES • BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED i REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED,the policy(les)must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorseinent(s) _ 1 PRODUCER • CONTACT NAME: Tom I LLaldunski I Hart Insurance Agency ^ Medford pppHONE FAX PO Box 1240 SHONE (541) 7794232 (AIC,Nol: ADDRESS: Grants Pass OR 97528 INSURER(S)AFFORDING COVERAGE NAIL U INSURER A:Berkley Aspire 31295 INSURED (541) 772-1945 INSURER a: Pressure Point Roofing Inc INSURER C: i 5235 Rainbow Drive INSURER R: I Central Point OR 97502 INSURER Ea INSURER F: 1 COVERAGES CERTIFICATE NUMBER:Cart ID 18665 REVISION NUMBER: • THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD 1 INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT]OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY.THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS. { EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR LTR TYPE OF INSURANCE ADPL SUER INSR WVD POLICY NUMBER POLICY EFF POLICY EXP (MMroDIYvyvl (MMIDpIYYYY) LIMITS A X COMMERCIALGENERAI.LIABILITY • EACH OCCURRENCE $ 1,000,000 I DAMAGE TO RENTED CLAIMS-MADE n OCCUR X X CGL0123510 03/29/2021 03/29/2022 pREMISES(Ea occurrence) 5 100,000 1 MED EXP(Any ane person) $ 5,000 I PERSONAL&ADV INJURY $ 1,000,000 GEM.AGGREGATE LIMITAPPLIESPER: GENERAL AGGREGATE $ 2,000,000 } I POLICY JE El PROCT- I ILOC PRODUCTS-COMPIOPAGG $ 2,000,000 OTHER: COMBINED SINGLE LIMIT 1 AUTOMOBILE LIABILITY (Eaeccident) $ I ANY AUTO • • BODILY INJURY(Per person) $ r OWNED SCHEDULED BODILY INJURY(Par accident) $ ` r AUTOS ONLY _ AUTOS PROPERTY DAMAGE HIRED NO NEY (Per accident) $ AUTOS ONLY _ AUTOS ONLY $ —e I A X UMBRELLA X OCCUR C10123511 03/29/202103/29/2022 EACH OCCURRENCE $ 2,000,000 EXCESS LUAU CLAIMS-MADE AGGREGATE $ • 2,000,000 • DED RETENTIONS ( $ I WORKERS COMPENSATION I PER ETH AND EMPLOYERS'LIABILITY , YIN E.L,EACH ACCIDENT $ r ANYPROPRIETORIPARTNERIEXECUTIVE nNIA • (Mandatorylory In NH) OFFICEEREXCLUDEDI EL,DISEASE-EA EMPLOYEE 5 In If yes,describe under E.L.DISEASE-POLICY LIMIT $ DESCRIPTION OF OPERATIONS below l . . ,. I • • [-- : . . I DESCRIPTION OF OPERATIONS ILOCATIONS I VEHICLES(ACORD 101,Additional Remarks Schedule,may he attached limo re space Is requ)rod) S I -', Certificate holder is additional insured per forms,attached: 1.807..01/17 Additional Insured Primary and Non Contributory Including Completed Operations, CG2010 04/13 Additional Insured Per Written i Contraot, CG2037 04/13 Additional Insured Completed Operations Per Written Contract, L404,05/09 Per, E Project Aggregate, and L609 05/09 Waiver . r additional insured: The City;of:Ashland, Oregon, its officers,: agents and employees with respect to I claims arising out the_•of_the provision of work under agreement r I CERTIFICATE HOLDER CANCELLATION L. SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVis1ONS. ' City of Ashland r. AUTHORIZED REPRESENTATIVE 9D North Mountain Avenue ,,/U - 3' 86)16r Ashland OR 97520 ©1988.2015 ACORD CORPORATION. All rights reserved. r i • ACORD 25(2016103) The ACORD name and logo are registered marks of ACORD POLICY NUMBER; COMMERCIAL GENERAL LIABILITY THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. ADDITIONAL INSURED M PRIMARY AND NONCONTRIBUTORY AUTOMATIC STATUS WHEN REQUIRED IN CONTRACT OR AGREEMENT (Including Completed Operations) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE !! ' 1 Date: - A. Section II-Who is An Insured Is amended to include as an additional insured any person or organization for whom you are performing operations when you and such person or organization have agreed in writing in a contract or agreement that such person or organization be added as an additional insured on your polioy. Such person or organization Is an additional Insured only with respect to liability for"bodily injury","property damage" or"personal end advertising injury"caused,in whole or In part,by; 1. Your acts or omissions,or the acts or omissions of those acting on your behalf in the performance of your ongoing operations for the additional Insured;or 2. "Your work"and included in the"products-completed operations hazard". but only for"occurrences"or coverages not otherwise excluded in the Coverage Part to which this endorsement applies. However the insurance afforded to such additional Insured: 1. Only applies to the extent permitted by law;and 2. Will not be broader than that which you are required by the contract or agreement to provide for such additional Insured. B. Status as an additional insured for the person or organization to which this endorsement applies commences during the policy period and after such written contract or agreement has been executed. C. With respect to the insurance afforded to the additional insured,the following additional exclusions apply: This insurance does not apply to: 1. "Bodily injury","property damage","personal and advertising injury"or medical payments arising out of the rendering of, or the failure to render, any professional architectural, engineering or surveying services, including a. The preparing, approving, or failure to prepare or approve, maps, shop drawings, opinions, reports, surveys,field orders,change orders or drawings and specifications;or b. Supervisory,inspection,architectural or engineering activities This exclusion applies even if the claims against any insured allege negligence or other wrongdoing in the supervision, hiring, employment, training or monitoring of others by that Insured, If the "occurrence" which oaused the"bodily injury"or"property damage", or the offense which caused the "personal and advertising Injury",involved the rendering of or the failure to render any professional architectural,engineering,or surveying services. 2. "Bodily Injury"or"property damage"Included in the"products-completed operations hazard" and arising out of"your work"that was completed by or on behalf of any Insured prior to the date shown in the Schedule of this endorsement. L607(01117) Includes copyrighted material of Insurance Services Office,Inc.,with Its permission. Page 1 of 2 • CGL 0123510-20 03/29/20 1195 12/22/20 ' POLIC', NUMBER: 0123510-20 COMMERCIAL GENERAL LIABILITY CG 20 10 04 13 • THIS ENDOHSEMHNx CHANGE'S THE POLICY. PLEASE II= IT CAREFULLY. ADDITIONAL INSURED -- OWNERS, LESSEES OR CONTRACTORS ^ SCHEDULED PERSON OR ` ORGANIZATION I This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional insured Persons) or Organization(s) . Per Written Contract I Looation(s) Of Covered Operations Per written contract (Information required to complete this Schedule, if not shown above, will be shown in the Declarations.) A. Section II - Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule,1 but only with respect to lia- bility for "bodily injury", "property damage" or "personal and advertising I injury" caused, in whole or in part, by: I 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured(s) at the location(s) designated above, However: I 1. The insurance afforded to such additional insured only applies to the extent { permitted by law; and 2. If coverage provided to the additional insured is required by a contract or I agreement, the insurance afforded to suchlac(ditional insured will not be broader than that which you are required by the contract or agreement to provide for such additional Ansured. B, With respect to the insurance afforded to these additional insureds, the follow- ing additional exclusions apply: This insurance does not apply to "bodily injury" or "property damage" occurring after; • 1. All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or,on behalf of the additional insured(s) at the location 1 of the covered operations has been completed; or I 2. That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another con- tractor or, subcontractor engaged in performingoperations for principal as 1 a part of the same project. : j, 1 C. With respect to the insurance afforded to these additional insureds, the following is added to section III .. Limits Of insurance: ' i 1 I CG 20 10 04 13 Copyright, Tnsurance services Office, Tnc,, 2012 Page 1 of 2 I { I 1 r I . I I • D. With respect to the Insurance afforded to the additional Insured,the following is added to Section III—Limits of Insurance: The most we will pay on behalf of the additional Insured is the amou t of insurance: 1. Required by the contract or agreement you have entered Into witlh the additional insured;or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever Is less. This endorsement shall not inorease the applicable Limits of Insurance.shown In the Declarations. E. The following condition Is added to 4.a.of Other Insurance of Section IV-Commercial General Liability Conditions: if required in a written contract, the Coverage Part to which this endorsement applies Is primary and noncontributory in the event of an"occurrence"caused,in whole or in part,by your ants or omissions, or the acts or omissions of those acting on your behalf that: 1. Occurs while performing ongoing operations for the additional Insured,or 2. Is included In the"products-completed operations hazard"and arises out of"your work"that was completed by or on behalf of any Insured after the date shown In the Schedule of this endorsement, All other terms and conditions remain unchanged, Le07(01/17) Includes copyrighted material of Insurance Services Office,inc.,with Its permission, Page 2 of 2 CGL 0123510 -20 03/29/20 f!SO 12/22/20 POLICY NUMBER: 0123510-20 COMMERCIAL GENERAL LIABILITY CG 20 37 04 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREVULLY. ADDITIONAL INSURED OWNERS LESSEES. OR CONTRACTORS - COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART � I PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Per Written contract Location And Description Of Completed Operations Per written contract Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Seotion TI - Who Is An Insured is amended to include as an'additional insured the person(s) or organization(s) shown in . the Schedule, but only with respect to liability for "bodily injury or "property damage" caused, in whole or in part, by "your work" at the location designated and described.in the Schedule of this endorsement performed for that additional insured and included in the "products-completed operations hazard". However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you axe required by the contract or agreement to provide for such additional insured. , B. With respect to the insurance afforded to these additional insureds, the following is added to Seotion III - Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount • of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. ' 1 This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. I � • l I CG 20 31 04 13 Copyright, Insurance Oarvices Office, Inc., 2012 Page 1 of 1• • • • If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the dditional insured is the amount of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable Limits of Insurance shown in the Declarations; whichever is less. This endorsement shall not increase the applicable Limits of Insurance shown in the Declarations. • Cc 20 10 09 13 copyright, Insurance Services Office, /rm., 2012 Page 2 of 2 COMMERCIAL GENERAL LIABILITY THIS ENDORSEMENT CHANGES THE POLICY, PLEASE READ IT CAREFULLY. CONSTRUCTION PROJECT GENERAL AGGREGATE LIMIT WHEN REQUIRED BY CONTRACT AND MAXIMUM PER POLICY GENERAL AGGREGATE LIMIT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Limits Of Insurance Maximum Per Policy General Aggregate Limit $5,000,000 A. For all sums whioh the Insured becomes legally obligated to pay as damages caused by"occurrences"under Section i - Coverage A- Bodily Injury And Property Damage Liability, and for all medical expenses caused by accidents under Section 1 - Coverage C-Medicai Payments, which can be attributed only to ongoing operations at a single construction project: 1. A separate Construction Project General Aggregate Limit applies to each construction project when required In a written construction contract or agreement, and that limit Is equal to the amount of the General Aggregate Limit shown in the Declarations, 2. The Construction Project General Aggregate Limit is the most we will pay for the sum of all damages under Coverage A, except damages because of "bodily Injury's or "property damage" included In the "products-completed operations hazard",and for medical expanses under Coverage G regardless of the number of: a. Insureds; b. Claims made or"suits"brought;or c. Persons or organizations making claims or bringing"sults", 3. Any paymentsmade under Coverage A for damages or under Coverage C for medical expenses shall reduce the Construction Project General Aggregate Limit for that construction project. Suoh payments shall not reduce the General Aggregate Limit shown in the Declarations nor shall they reduce any other Construction Project General Aggregate Limit for any other const?lotlon project, 4. The limits shown in the Declarations for Each Occurrence, Damage To Premises Rented To.You and Medical Expense continue to apply. However, instead of being subject to the General Aggregate Limit shown in the Declarations, Suoh limitswill be subject to the applicable Construction Project General Aggregate Limit, 5. The Maximum Per Policy General Aggregate Limit shown In the Schedule Is the most we will pay for the sum of all Construction Project General Aggregate Limits and the General Aggregate Limit shown in the Declarations regardless of the number of: a. Insureds; b. Claims made or"suits"brought; c. Persons or organizations making claims or bringing"sults';or d. Construction projects. • L404(06109) Includes copyrighted material of Insurance Services Office,Ino„with tis permission. Page 1 of 2 • B. For all sums which the Insured becomes legally obligated to pay as damages caused by"occurrences"under Section i - Coverage A- Bodily Injury And Property Damage Liability, and for all medical expenses caused by accidents under Section I-Coverage C Medical Payments,which cannot be attributed only to ongoing operations at a single construction project: 1. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the amount available under the General Aggregate Limit shown In the Declarations or the Products-Completed Operations Aggregate Limit shown in the Declarations,whichever is applicable;and 2. Such payments shall not reduce any Construction Project General Aggregate Limit. C. When coverage for liability arising out of the "products-completed operations hazard" is provided, any payments for damages because of"bodily Injury or "property damage" included In the"products-completed operations hazard" will reduce the Products-Completed Operations Aggregate Limit shown in the Declarations, and not reduce the General Aggregate Limit shown in the Declarations nor the Construction Project General Aggregate Limit. D. If the applicable construction project has been abandoned, delayed, or abandoned and then restarted, or if the authorized contracting parties deviate from plans, blueprints, designs, specifications, or timetables, the project will still be deemed to be the same construction project. B. The provisions of Section IIi - Limits Of insurance not otherwise modified by this endorsement shall continue to apply as stipulated. All other terms and conditions of this policy remain unchanged, • i . L404(05/08) Includes copyrighted material of Insurance Services Office,Inc.,with its permission, Page 2 of 2 • • • • COMMERCIAL GENERAL LIABILITY • THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US -AUTOMATIC STATUS WHEN • REQUIRED IN CONTRACT OR AGREEMENT This endorsement modifies insurance provided under the following: . COMMERCIAL GENERAL LIABILITY COVERAGE PART The following is added to 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV - Commercial General Liability Conditions: We waive any right of recovery we may have against any person or organization because of payments we make for injury or damage caused, In whole or in part, by your acts or omissions, or the acts or omissions of those acting on your behalf in the performance of your ongoing operations or"your work"done under a written contract withthat person or organization and included in the"products-completed operations hazard".This waiver applies only when you and that person or organization have agreed to such waiver In writing in a contract or agreement. • All other terms and conditions of this policy remain unchanged. •• • • • • • • • • L609(05/09) Includes copyrighted material of Insurance Services Office,inc.,with itsperrnisslon. S ACORD CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) `� v I 11/29/2021 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. . If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). • PRODUCER CONTACT Hart Insurance Agency -, Medford PHONE Kristi Dolmage FAX PO Box 1240 IANC.No.Extl: (541) 779-4232 (A/C,No): A MAIL kdolmage@hartinsurance.com Pass OR 97528 ADDRESS: geC4hartinsurance.com INSURER(S)AFFORDING COVERAGE NAIC# INSURER A:Mutual of Enumclaw Insurance C 14761 INSURED (541) 772-1945 J INSURERS: Pressure Point Roofing Inc - INSURER C: 5235 Rainbow Drive INSURERD: Central Point OR 97502 ' INSURERE: INSURER F: COVERAGES CERTIFICATE NUMBER:Cert ID-21090 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUBR POLICY EFF POLICY EXP LIMITS LTR INSD WVD POLICY NUMBER IMM/DDIYYYY) IMM/DD/YYYYI COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ DAMAGE TO RENTED CLAIMS-MADE OCCUR PREMISES(Ea occurrence) $ _ MED EXP(Any one person) $ - PERSONAL&ADV INJURY $ GEN'LAGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ POLICY PRO- JECT LOC PRODUCTS-COMP/OP AGG $ OTHER: $ AUTOMOBILE LIABILITY '. COMBINED SINGLE LIMIT $ 1,000,000 (Ea accident) A X ANY AUTO Y CPP0002914 12/06/202112/06/2022 BODILY INJURY(Per person) $ OWNED SCHEDULED BODILY INJURY(Per accident) $ AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $ AUTOS ONLY AUTOS ONLY (Per accident) $ ' UMBRELLA LIAB — OCCUR EACH OCCURRENCE $ EXCESS LIAB CLAIMS-MADE AGGREGATE $ DED RETENTION$ $ WORKERS COMPENSATION PER OTH- AND EMPLOYERS'LIABILITYY/N STATUTE ER ANYPROPRIETOR/PARTNER/EXECUTIVE N/A E.L.EACH ACCIDENT $ OFFICER/MEMBER EXCLUDED? (Mandatory in NH) E.L.DISEASE-EA EMPLOYEE $ If yes,describe under • DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT $ - $ $ DESCRIPTION OF OPERATIONS I LOCATIONS/VEHICLES(ACORD 101,Additional Remarks Schedule,may be attached If more space Is required) Certificate holder is listed as additional insured where required by written contract per attached form EA9911 ,— CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN City of Ashland ACCORDANCE WITH THE POLICY PROVISIONS. 20 B Main Street AUTHORIZED REPRESENTATIVE Ashland OR 97520 � G J ©1988-2015 ACORD CORPORATION. All rights reserved. ACORD 25(2016/03) The ACORD name and logo are registered marks of ACORD n,..e 1 ..f 1 Kariann Olson From: Kristi Dolmage<kdolmage@hartinsurance.com> Sent: Monday,November 29,2021 11:08 AM To: Kariann Olson Subject: Renewal Certificate Attachments: CERT City_of Ashland_680494_436999.pdf [EXTERNAL SENDER] Attached is the renewal certificate of insurance for Pressure Point Roofing Inc.for their Auto Insurance Only. If you have any questions,,please feel free to contact our office. Thank you, Kristi Dolmage CISR 0 Commercial Lines Department P: 541.779.4232 F: 541.772.3963 This electronic message may contain information that is privileged, confdential or otherwise protected from disclosure to anyone other than its intended recipient(s). Any dissemination or use of this electronic message or its contents by ' persons other than the intended recipient(s) is strictly prohibited, and may be unlawful. If you have received this electronic transmission in error, please reply immediately to the sender so that we may correct our internal records, then delete the original message. 1