HomeMy WebLinkAbout2000-001 Contract-Overhead DoorCITY OF ASHLAND PERSONAL SERVICES CONTRACT FOR SERVICES LESS THAN $15,000
CITY OF ASHLAND. (CITY)
20 East Main Street
Ashland, Oregon 97520
Telephone: (541) 488-6002
~AX: (541) 458-5311
3. BEGINNING DATE: ASAP
L ¶4 .COMPENSATION: $849.00
CONSULTANT: Overhead Door Company
Address: 1945 Delta Waters Road
Medford, OR 97504
Telephone: 770-5577
FAX: 779-5'i50
¶3. COMPLETION DATE:
¶i SERVICES TO BE PROVIDED: Remove existing door and replace with new 24 ga. Steel prepairtted (white)
hood Includes Additional Curtain Side Locks, #3 Chain Hoist and High wind load
ADDITIONAL TERMS:
CTY AND CONSULTANT AGREE:
· AIr Costs by Coesuitant Consultant shall, at ds own risk and expense, perform the personal services described above and,
,rfless otherwise specified, furnish all labor, equipment and materials required for the proper performance of such service
Qualibed Work: Consultant has represented, and by entering into this contract now represents, that air personnel assigned to
he work required under this contract are fully qualified to perform the service to which they w~l[ be assigned in a skirled and
,vorkedike manner and, if required to be registered, hcensed or bonded by the State of Oregos, are so registered, licensed and
Complebon Date Consultant shall stad performing the service under this contract by the beginning date indicated above and
omplete the service by the completion date indicated above
,, C~o~ensetiol~ City shall pay Consultant for service performed, including costs and expenses, the sum specified above Once
work commences, invoices shall be prepared and submiRed by the tenth of the month for work completed in the prior month.
~ayments shall be made within 30 days of the date of the invoice Should the contract be prematurely terminated, payments
'~e made for work completed and accepted to date of termination.
~ Ownership of Documents All documents prepared by Consultant pursuant to this contract shall be the property of City
~ Statutory Requireme. nts: ORS 279 312, 279.314, 279 316 and 279 320 are made part of this contract
Indemmflcation: Consultant agrees to defend, indemnify and save City, ds officers, employees and agents harmless from any
¢~d all losses, claims, actions, costs, expenses, judgments, subrogations, or other damages resulting from injury to any person
qctuding injury resulting in death), or damage (including loss or destruction) to property, of whatsoever nature arising out of or
r~c~dent to the performance ef this contract by Consultant (including but not limited to, Consultant's employees, agents, and others
~-es~gnated by Consultant to perform vv~rk or services attendant to this contract). Consultant shall not be held responsible for any
~sses, expenses, claims, subrogations, actions, costs, judgments, or ether damages, directly, solely, and approximately caused
; y the negligence of City
¢ Termination This contract may be terminated by City by giving ten days written notice to Consultant and may be terminated
~ y Consultant should City fail substantially to perform ds obhgations through no fault of Consultant
· independent Contractor Status Consultant is an independent contractor and not an employee of the City C~nsultant shall
ave the complete responsibility for the performance of this contract Consultant shall provide workers' compensation coverage as
equ;red in ORS Ch 656 for all persons employed to perforn~ work pursuant to this contract Consultant is a subject emptoyer that
,¢~ii vomply with ORS 656017
,3 ~n~ent and Su,bcontracts Consultant shal! not asstgn this contract or subcontract any portion of the work without the
,,/r ~tten consent of City, Any at~empted assignment or subcontract without wlitten consent of City shall be void Consultant shall
r,e ~[y responsible for the acts or omissions of any assigns or subcontractors and of all persons employed by them, and the
~ppr~vai by City of any assignment or subcontract shall not create any contractual reiahon between the asSignee or subcontractor
;:)NSULTANT:
ts
CITY OF ASHLAND:
City Administrator Date
BY
Director of Finance
CONTENT REVIEW:
Purchase Order #
Date
(City Dept. Head Date:
C!TY OF ASHLAND PERSONAL SERVICES CONTRACT <$15,000 (p:forms~-shrtps fk wlxJ)(rev'd 12~J9)
OAS (IN¥'IH$¥ 0~$ ~, [~,~e ](Vzl t'O:;~[ q.~ O0/c~O/[O