HomeMy WebLinkAbout2000-041 Contract - Marquess & Associates CITY OF ASHLAND PERSONAL SERVICES CONTRACT FOR SERVICES LESS THAN $15,000~/y ~/~'
CITY OF ,ASHLAND, (CITY) CONSULTANT: Marquess and Associates, Inc
20 E. Main St. Address: PC Box 490
Ashland, Oregon 97520 Medford, OR 97501
(541) 488-6002 FAX: (541) 488-5311 Telephone: 541-772-7115 FAX: 541-779-4079
AGREEMENT DATE: 11110199
¶3. BEGINNING DATE: 1118199
¶4. COMPENSATION: $2,500.00
¶3. COMPLETION DATE: 12131199
¶1. SERVICES TO BE PROVIDED: Survey Work per attached proposal dated 11-2-99, except that the fee
indicated in the first sentence of page 2 shall be billed on an "actual time and materials but not to exceed
$2500.00" basis instead of a "probable cost fee" basis. The extent of area to be surveyed shall be limited to
areas not already surveyed by OBEC Engineering and OTAK, Inc. within the past twelve months.
ADDITIONAL TERMS:
Fr-c_
CITY AND CONSULTANT AGREE:
1. All Costs by Consultant: Consultant shall. at its own risk and expense, perform the personal services described above and, unless otherwise
specified. furnish all labor, equipment and materials required for the proper performance of such service.
2. Qualified Work: Consultant has represented, and by entering into this contract now represents, that all personnel assigned to the work required
under this contract are fully qualified to perform the service to which they will be assigned in a skilled and workerlike manner and, if required to be
registered, licensed or bonded by the State of Oregon, are so registered. licensed and bonded. Consultant shall also procure and maintain a current
City of Ashland business license.
3. Coml~letion Date: Consultant shall start performing the service under this contract by the date indicated above and complete the service by the
completion date indicated above.
4. Compensation: City shall pay Consultant for service performed, including costs and expenses, the sum of specified above. Once work
commences, invoices shall be prepared and submitted by the tenth of the month for work completed in the prior month. Payments shall be made
within 30 days of the date of the invoice. Should the contract be prematurely terminated payments will be made for work completed and accepted to
date of termination.
5. Ownershio of Documents: All documents prepared by Consultant pursuant to this contract shall be the property of City.
6. Statutory Rer~uirements: ORS 279.312, 279.314, 279.316 and 279.320 are made part of this contract,
7. Indemnification: Consultant agrees to defend, indemnif, j and save City, its officers. employees and agents harmless from any and all losses,
claims. actions, costs, expenses, judgments, subrogations, or other damages resulting from injury to any person (including injury resulting in death,)
or damage (including loss or destruction) to property, of whatsoever nature adsing out of or incident to the performance of this contract by Consultant
(including but not limited to, Consultant's employees. agents, and others designated by Consultant to perform work or services attendant to this
contract.) Consultant shall not be held responsible for any losses, expenses, claims, subrogations, actions, costs, judgments, or other damages,
directly, solely, and approximately caused by the negligence of City.
8. Termination: This contract may be terminated by City by giving ten days written notice to Consultant and may be terminated by Consultant should
City fail substantially to perform its obligations through no fault of Consultant.
9. Independent Contractor Status: Consultant is an independent contractor and not an employee of the City. Consultant shall have the complete
responsibility for the performance of this contract. Consultant shall provide workers' compensation coverage as required in ORS Ch 656 for all
persons employed to perform work pursuant to this contract and pdor to commencing any work, Consultant shall provide City with adequate proof of
workers' compensation coverage. Consultant is a subject employer that will cemply with ORS 656.017.
10. Insurance: Consultant shall, at its own expense, at all times during the term of this agreement. maintain in force a comprehensive general
liability policy including coverage for contractual liability for obligations assumed under this Contract, blanket contractual liability, professional errors
and omissions, products and completed operations and comprehensive automobile liability including owned and non-owned automobiles. The
liability under each policy shall be a minimum of $500,000 per occurrence (combined single limit for bodily injury and property damage claims) or
$500,000 per occurrence for bodily injury anti $100,000 per occurrence for property damage. Liability coverage shall be provided on an "occurrence"
not "claims" basis. The City of Ashland, its officers. employees and agents shall be named as additional insureds. Certificates of insurance
acceptable to the C~ty shall be filed with City's Risk Manager prior to the commencement of any services by Consultant under this agreement. These
certificates shai~ contain provision that coverages afforded under the policies can not be canceled and restrictive modifications cannot be made until
at least 30 days prior wdtten notice has been given to City. A certificate which states merely that the issuing company '~vill endeavor to mail" written
notice is unacceptable.
11. AssiGnment and Subcontracts: Consultant shall not assign this contract or subcontract any portion of the work without the written consent of
City. Any attempted assignment or subCOntract without written COnsent of City shall be void. Consultant shall be fully responsible for the acts or
omissions of any assigns or subcontractors and of all persons employed by them, and the approval by City of any assignment or subCOntract shall
not create any contractual relation between the assignee or subcontractor and City.
CONSULTANT: CITY OF ASHLAND:
Pu~haseO er~ ~
CI~ OF ASH~ND PERSONAL S V ( ~
Fed. ID~ Coding: ~~~ (forCi~pu~osesonly)
ER ICES CONTRACT <$~O0 (p:~s~-sh~ps.~)(mv'd 7~3)
F:\USER~ENG~Hillah Temple~topocontract.doc
1120 EAST JACKSON P.O. BOX 490 MEDFORD, OREGON 97501
November 2, 1999
CONSULTING ENGINEERS
TELEPHONE: (541) 772-7115
FAX: (541) 779-4079
Greg Scoles, Assistant City Administrator
20 East Main Street
Ashland, Oregon 97520
Site Survey - Hillah Temple
MAI Job No. 1-7225
Dear Mr. Scoles:
We have been requested, by Berry Amhitects of Eugene, to provide you with an estimate for
surveying services for the Hillah Temple site and the adjacent public restrooms to the north. We
would be pleased to perform these services for you, outlined as follows:
SCOPE OF SERVICES:
A complete topographic survey of the existing Hillah Temple site located within tax lot 2100 of
Assessors Map No. 39 IE 9 BC and a portion of 39 IE 9 BB, tax lot 7500 where the existing
public restrooms are located. Mapping of all existing conditions and improvements will include:
Buildings, utilities, walkways, parking, curb and gutter, and access driveways.
Adjacent street and creek, bridges, stairways, and drainage structures.
Topography denoted by spot elevations and one-foot contour intervals.
Significant topographic features.
Landscape trees, retaining walls, encroachments, and solar access.
It has been brought to our attention that a boundary survey was performed by the City of
Ashland Engineering Dept., although the information is not of public record at this time. If that
information is provided to us, we will accurately depict the property boundaries on the mapping
at no additional charge. However, if we are asked to determine boundary information on our
own, this will be an additional expense, which could be significant due to a history of conflicting
deeds and availability of sufficient survey control in this area. If requested to do so, we can
provide these services on a negotiated fee basis.
All deliverables will be furnished in an electronic AutoCAD R14 drawing format as well as on
printed media at an appropriate engineering scale.
Mr. Greg Scoles
November 2~ 1999
Page 2
FEES:
We propose to provide the above services for the probable cost fee of Two Thousand Five
Hundred Dollars ($2,500.00).
Probable cost fees given by the Surveyor shall be considered as estimates only and shall not be
construed as guarantees that the work can be done for the amount thereof. The Surveyor will
endeavor to keep the actual cost of the work as low as may be consistent with the purpose of the
project and with proper workmanship and materials.
The above fee does not include reimbursable expenses for printing, permits and fees, mileage,
telephone calls, fax, photographs, etc. All additional work that is outside the scope of services as
described shall be paid for at the hourly rate schedule enclosed as Exhibit A which is valid until
December 31, 1999.
As compensation for services rendered, a billing will be sent on the first day of each month showing
the hours and rates of the various classifications of personnel working on the project. Payment of
the billings must be made by the 20th of each month. Late payments will be subject to a service
charge of 1.5% per month on the unpaid balance. In the event that work is stopped on this project,
the hourly rate shall determine the engineering fee.
If, after a definite scheme has been approved, the Owner or goveming Municipality or Agency
makes a decision, which for its proper execution involves additional services and expense for
changes in or addition to drawings, specifications or other documents, or changes in methods or
procedure or of handling the work, or if the Owner or Contractor delay the work, or if either is
delinquent or becomes insolvent, then the Engineer shall be equitably paid for such additional
services and expense.
This letter is written as an Engineering Proposal and Agreement. An acceptance line is provided for
your signature. Please return one signed copy for our files.
In the event suit or action is instituted to entbrce this agreement or any terms hereof, or in the event
of any appeal from st~t, action or proceeding, the prevailing party shall be entitled to such sums as
the court may adjudge reasonable as attomey's fees in such suit, action or appeal.
This proposal, if not signed and remmed within 60 days of the above date, will become invalid and
must be renegotiated.
Mr. Greg Scoles
November 2, 1999
Page 3
If you have any questions or I can be of any other assistance, please don't hesitate to call.
Respectfully,
MARQUESS & ASSOCIATES, INC.
Shawn E. Kampmann
Professional Land Surveyor
SEK/RCC/pc
Enclosure: Engineering Fee Schedule
sek\l-7225Prop.doc
Rand~C.~leveland, P.E.
President
AUTHORIZATION
Approved By Date
1120 EAST JACKSON P.O. BOX 49O MEDFORD, OREGON 97501
EXHIBIT "A"
August 1, 1999
ENGINEERING FEE SCHEDULE
CONSULTING ENGINEERS
TELEPHONE: (541) 772-7115
FAX: (541) 779-4079
Executive Engineer ....................................................$102.00 per hour
Principal Engineer .....................................................$ 92.00 per hour
Geotechnical Engineer .................................................$
Hydrology Engineer ....................................................$
Senior Engineer .........................................................$
Structural Project Engineer ............................................$
Project Engineer ........................................................$
Registered Land Surveyor/Senior Engineering Technician .....$
Design Engineer/Senior Survey Technician II .....................$
Designer II ...............................................................$
Soils Field Technician/Senior Survey Technician I ...............$
Designer I/Soils Lab Technician/Survey Technician III .........$
Drafter II/Survey Technician II ......................................$
Drafter I/Survey Technician I .......................................$
Inspector .................................................................$
AutoCAD Operations ..................................................$ 20.00 per hour
Survey Crew - 2-Person Party ........................................$105.00 per hour
Survey Crew - 3-Person Party .......................................$158.00 per hour
Word Processor .........................................................$ 38.00 per hour
Mileage ...................................................................$ 0.35 per mile
Out-of-Pocket Expenses .................................................Actual Cost
Material Testing Services ...............................................Schedule Provided On Request
92.00 per hour
81.00 per hour
81.00per hour
72.00 - $77.00 per hour
70.00- $75.00per hour
63.00 - $70.00 per hour
60.00 - $65.00 per hour
58.00- $63.00per hour
54.00per hour
52.00 - $57.00 per hour
48.00 per hour
46.00 per hour
52.00per hour
PAYMENT: Payment on the billings must be made on or before the 20th day of each month.
A CHARGE OF 1.5% PER MONTH (18% ANNUAL PERCENTAGE RATE) WILL BE ADDED
AFTER 30 DAYS UNLESS PRIOR ARRANGEMENTS ARE MADE.