HomeMy WebLinkAbout2000-064 Contract - KittelsonKITTEL~
CITY OF
CITY OF ASHLAND, (CITY)
20 East Main Street
Ashland, Oregon 97520
Telephone: (541) 488-6002
FAX: (541) 488-5311
&3, BEGINNING DATE: February 24, 2000
13 2ooo
T FOR SERVICES LESS THAN $1S,OO0
CONSULTANT: Ki~non& Associates, Inc. L'~
Address: 610 SW Alder #700
Portland, OR 97205
Telephone: (503) 228-5230
F/O(: (503}273-8169
COMPLETION DATE: June 1,2000
~.4. COMPEENSlTION: Time and rnatodal9 not to e×eeed $1 .S00.
&l . SERVICES TO BE PROVIDED: TraffiO Engineering consulting for the Ashland Public Library Project; general
consulting services related to required planning application and design,
ADDITIONAL TERMS:
CITY AND CONSULTANT AGREE:
1, All Costs by Consultant: Consultant shall, at its own risk and expense, pedorm the personal services described above and,
unless otherwise specified, furnish all labor, equipment end materials required for the proper performance el' such service.
2. Qualified Work; Consultant has represented, and by entering into this contract now represents. that ell personnel assigned to
the work required under this contract are fully qualified to perform the service to which they will be assigned in a skilled and
workedike manner and. if required to be registered, licensed or bonded by the State of Oregon, are so regislere<l, licensed and
bonded.
3, Completion Date: Consultant shall start performing the service under this contract by the beginning date indicaled above and
complete the ,service by the completion date indicated above.
4. Compensation: City shall pay Consultant for service performed, including costs end expenses, the sum specified above. Once
work commences, invoices shall be prepared end submitted by the tenth of the month for work completed in The prior month.
Payments shall be made within 30 days of the date of the invoice. Should the contract be prematurely terminated, payments will be
made for work completed and accepted to date of termination,
5. Ownership of DOcumentS: All documents prepared by Consultant pursuant to this contract shall be the property of City.
6. Statutory Requirements: ORS 279.312, 279.314, 279.316 and 279.320 are made part of this contract.
7. Indemnification: Consultant agrees to defend, indemnify and save City, its officers, employees and agents harmless from any
and all losses, claims. actions, costs, expenses, judgments, subrogations, or other damages resulting from injury to any person
(including injury resulting in death), or damage (including loss or destruction) to property. of whatsoever nature adsing out of or
incident to the performance of this contract by Consultant (including but not limited to, Consultent's employees, agents, and others
designated by Consultant to perform work or services attendant to this contract). Consuitant shall not be held responsible for any
losses, expenses, claims, subrogations, actions, cos[s, judgments, or other damages, directly, solely. and approximately caused by
the negligence of City.
8. TerminatiOn; This contract may be terminated by City by giving ten days written notice to Consultant and may be terminated by
Consultant should City fail ~ubstantially to perform its obligations through no fault of Consultant.
9. I. nSieoendent Contractor Status; Consultant is an independent contractor and not an employee of the City. Consultant shall
have the complete responsibility for the performance ct this contract. Consultant shall provide workers' compensation coverage as
required in ORS Ch 656 for all persons employed to peiform work pursuant to this contract. Consultant is a subject employer that
will comply with ORS 658.017.
1 O. Asaionment and SubcontracLs; Consultant shall not assign [his contract or subcontract any portion of the work without the
written consent of City. Any attempted ass~gnmenl or subc, ontrac~ without written consent of City shall be void. Consultant shall be
fully responsible for the acts or omissions of any assigns or subcontractors and of all persons employed by them. and the approval
by City of any assignment or subcontract shell not create any contractual relation between the assignee or subContractor and City.
Fed.,O#
DATE
OR
CITY OF ASHLAND:
City Administrator Date
BY
Director of Finance Date
CONTENT R~VI~cW; (City Dept. Head) Date:
PumhaseOrder# ~ ~
C4;~ling;/~,/~'~c'L~',~,~',~"'~'~,;?-/ c/ (for City purposes only)