HomeMy WebLinkAbout2000-120 Contract - Project ACITY OF ASHLAND CONTRACT
CITY OF ASHLAND, (CITY) CONTRACTOR: Project A, Inc.
20 E. Main St.
Ashland, Oregon 97520 Address: 340 A St
Ashland, OR 97520
(541) 488-5300 FAX: (541) 488-5311 Telephone:541-488-1702 FAX:541-488-1851
DATE OF AGREEMENT: See attached BEGINNING DATE FOR WORK: See attached addendum
addendum
COMPENSATION: See attached COMPLETION DATE: See attached addendum
addendum
WORK TO BE PROVIDED:
See attached addendum
ADDITIONAL TERMS: See attached addendum
CITY AND Contractor AGREE:
1. All Costs by Contractor: Contractor shall, at its own risk and expense, perform the work described above and, unless otherwise specified,
furnish all labor, equipment and materials required for the proper performance of such work.
2. Qualified Work: Contractor has represented, and by entering into this contract now represents, that all personnel assigned to the work
required under this contract are fully qualified to perform the work to which they will be assigned in a skilled and workerlike manner and, if
required to be registered, licensed or bonded by the State of Oregon, are so registered, licensed and bonded. Contractor shall also procure
and maintain a current City of Ashland business license.
3. Completion Date: Contractor shall start performing the work under this contract by the date indicated above and comptete the work by the
completion date indicated above.
4, Compensation: City shall pa'/Contractor for work performed, including costs and expenses, the sum specified above. Once work
commences, invoices shall be prepared and submitted by the tenth of the month for work completed in the prior month. Payments shall be
made within 30 days of the date of the invoice. Should the contract be prematurely terminated payments will be made for work completed
and accepted to date of termination
5. Ownership of Documents: All documents prepared by Contractor pursuant to this contract shall be the property of City.
6. Statutory Requirements: ORS 279.312, 279.314, 279.316 and 279.320 are made part of this contract.
7. indemnification: Contractor agrees to defend, indemnify and save City, its officers, employees and agents harmless from any and all
losses, claims, actions, costs, expenses, judgments, subrogations, or other damages resulting from injury to any person (including injury
resulting in death,) or damage (including loss or destruction) to property, of whatsoever nature arising out of or incident to the performance
of this contract by Contractor (including but not limited to, Contractor's employees, agents, and others designated by Contractor to perform
work or services attendant to this contract.) Contractor shall not be held responsible for any losses, expenses, claims, subrogations, actions,
costs, judgments, or other damages, directly, solely, and approximately caused by the negligence of City.
8, Termination: See attached addendum.
9. Independent Contractor Status: Contractor is an independent contractor and not an employee of the City. Contractor shall have the
complete responsibility for the performance of this contract. Contractor shall provide workers' compensation coverage as required in ORS Ch
656 for all persons employed to perform work pursuant to this contract and prior to commencing any work, Contractor shall provide City
with adequate proof of workers' compensation coverage. Contractor is a subject employer that will comply with ORS 656.017.
10. Insurance: Contractor shall, at its own expense, at all times during the term of this agreement, maintain in force a comprehensive general
liability policy including coverage for contractual liability for obligations assumed under this Contract, blanket contractual liability, products
and completed operations, owner's and contractor's protective insurance and comprehensive automobile liability including owned and non-
owned automobiles. The liability under each policy shall be a minimum of $500,000 per occurrence (combined single limit for bodily injury
and property damage claims) or $500,000 per occurrence for bodily injury and $100,000 per occurrence for property damage. Liability
coverage shall be provided on an "occurrence" not "claims" basis. The City of Ashland, its officers, employees and agents shall be named as
additional insureds. Certificates of insurance acceptable to the City shall be filed with City's Risk Manager prior to the commencement of any
work by Contractor under this agreement. These certificates shall contain provision that coverages afforded under the policies can not be
canceled and restrictive modifications cannot be made until at least 30 days prior written notice has been given to City. A certificate which
states merely that the issuing company "will endeavor to mail" written notice is unacceptable.
11. Assignment and Subcontracts: Contractor shall not assign this contract or subcontract any portion of the work without the written
consent of City. Any attempted assignment or subcontract without written consent of City shall be void. Contractor shall be fully responsible
for the acts or omissions of any assigns or subcontractors and of all persons employed by them, and the approval by City of any assignment
or subcontract shall not create any contractual relation between the assignee or subcontractor and City.
Fed. ID #
CITY OF ASHLAND:
Ci~dministrator
CO~'ENT REVIEW: (City Dept. HeadJ Date:
FORM REV/EW.. .(City AttorneyJ Date:
Coding.~( ~ ~ /~ ~ ~//~ ~ /'~/'~or City purposes on/y)
~'f.~-~'~ ,~-~'~'-- ~/
Web site Design, development, hosting and maintenance contract
between the City of Ashland and Project A
Addendum to Contract
Prepared by City of Ashland,
February 10, 2000
Contract Definition
Project A will provide the City of Ashland with two related services over a multi-year
period. Each of the services provided will operate under the same terms of this
agreement unless otherwise specified.
The first service will consist of hosting and server maintenance for all contents of the
internet site identified as www.ashland.or.us. This service will be identified hereafter as the
hosting agreement and a detailed definition of the service can be found in the scope of
work section of the agreement.
The second service will consist of design, development, deployment and internal training
for the content provided on the interact site identified as www.ashland.or.us. This service
will be identified hereafter as the development agreement and a detailed definition can be
found in the scope of work section of the agreement.
Scope of Work
The hosting agreement will include importation and storage of data, server monitoring,
hardware maintenance, maintaining interact connectivity for the domain, data back-up
and personnel available on-call to respond if needed. All new content that arises as a
result of the development agreement will be imported and stored as part of the hosting
agreement. Import and storage costs will not be a part of any scope of work under the
development agreement.
The development agreement will be conducted within seperate and specific scopes of
work that will adhere to the following process:
· The City, with input from Project A, will define a particular project or task.
· Project A will provide an estimate of expected timeframe and costs associated
with the task.
· Upon review and approval of the task estimates, an agreement will be signed to
indicate a mutual understanding of the work to be completed. All task agreements
will adhere to all applicable sections of this contract.
Fee Structure
Work done within the framework of the development agreement will be billed on an
hourly basis, at a rate of $75 per hour. The number of hours billed for development will
be based on the estimates provided in the individual task agreements. The City
understands that estimates are not considered firm agreements of the total development
cost for specific projects, and Project A will invoice for work completed on a "time and
materials" basis. It is further understood that Project A will not continue working on a
project if the actual development time exceeds the estimated development time without
prior written approval from the City.
Fees for services provided in the hosting agreement are billed monthly at a flat rate of
$250. This flat fee provides the City with 200 megabytes of storage space and 1000
megabytes of bandwidth to the site each month. Additional storage and bandwidth will
be tracked and billed by Project A quarterly. Additional storage will be billed at a rate of
$1.25 per megabyte per month. Additional bandwidth will be billed at a rate of $.10 per
megabyte per month.
Billing
Invoices will be sent monthly and will be due 30 days from the invoice date. Past due
amounts will be assessed a 1.5% penalty. Invoices will seperate the fees into catagories
for hosting and for development. The development fees will also be labeled to indicate
which particular task is being billed.
Contract Term
This contract has an expiration anniversary date of June 30, 2001. However, either party
has the right to terminate the contract at any time by giving a minimum of 60 days
written notice in advance of the anniversary date. If no termination notice is provided
prior to the 60 day notice period, the contract will automatically be extended for one
additional year with all original provisions applicable.
If the termination of the contract is initiated by Project A, an "exit plan" to enable future
web development and hosting by another firm must be submitted with the termination
notice and be mutually agreed upon before the acceptance of the termination. Fees for
providing this exit plan will be charged as a development item.
If either party to this agreement wishes to amend, add to, or otherwise modify this
agreement in any way, it shall be done in writing, subject to approval by both parties, and
attached to this agreement.
Agreement
The following signatures indicate an understanding of and agreement with the terms and
conditions of the contract.
City of Ashland
Title
Proj~, Inc.
Title
Date Accepted
Date Accepted
CITY OF ASHLAND
20 E. MAIN ST.
ASHLAND, OR 97520
VENDOR: 000712
PROJECT A. INC
340 A STREET
ASHLAND, OR 97520
SHIP TO:
PAGE i
07/27/00 ] ~
City' of Ashland
(541) 488-6002
20 E MAIN STREET
ASHLAND. OR 97520
FOB Point:
Terms: Net 30 days
Req, Del. Date:
Special lnst:
Req. No.:
Dem.: ADMINISTRATION
Contact: Greg Scoles
Confirming? N
Quainter' :Ur~tt Desc~q~tion Un~ Price Ext. Price
3LANKET PURCHASE ORDER
~e~ S~e Hosting 2000-2001 3 600 OC
~eb Site Development 2000-2001 25,000.0(
:~o~ ~ exceed $25 000.00
:
:
SUBTOTAL 28,600. OC
BILL TO: Account Payable TAX . OC
20 EAST MAIN ST FREIGHT .0C
541-552-2010 TOTAL 28,600.0C
ASHLAND, OR 97520
710.01.05.00.604100 28,600.00
CITY OF ASHLAND
20 E MAIN ST.
ASHLAND, OR 97520
(541) 488-5300
VENDOR: 000712
PROJECT A, INC
340 A STREET
ASHLAND, OR 97520
DATE
01266
SHIP TO: City of Ashland
(541) 488-6002
20 E MAIN STREET
ASHLAND, OR 97520
FOB Point:
Terms: Net 30 days
Req, Del. Date:
Special lnst:
Req. No.:
Dept.: ADMINISTRATION
Contact: Greg Scoles
Confirming? No
Quanti~ Unit ~.-~--~ Description Unit Price Ext, Price
THIS ISLA~ISED. D.D/flURCHASE ORDER ,
BLANKET PuR-C~ASE ORDER
Web Site Hosting 2000-2001~ 3,600.00
Requisition #2365 ~
Web Site Development 2000-2001~ Not to 25,000.00
exceed $25 000 00~ Requ s t On #2365
Additional charges for web site 10,000.00
deve 0pment ~
Per requisition 1623, Jan-July 2001
SUBTOTAL 38,600,00
BILL TO; Account Payable TAX 0.00
20 EAST MAIN ST FREIGHT 0.00
541-552-2010 TOTAL 38,600.00
ASHLAND, OR 97520
: AccoUnt Number AmoUnt Acc0unt Number; ; Am0Uht :;
E 710.01.05.00.604100 38,600.00
A~u~t~nonzecl ~5 gnature
VENDOR COPY
PROJECT A
SO FTWARE
SOLUTIONS
INTERNE?
SOLUTIONS
624 'A'
A~lo~d, Om~n 97520
voz 541/468-1702
[o~ 541/486-1851
800/8~9-76~9
ww'~.prQiaao.cem
City of Ashlnmi - Dynamic Interact System Devclopmcnt
Pro~ect Specific~(iona
City of Ashland
Web Development
Project Specifications
Project Definition
Pwject A will design, develop, nnd deploy a new look and feel for the City of Ashland World Wide
Web Site known as http:/!www.s*hlsna or.us/. In addition, Project A w/Il design, develop, deploy
and prey/ch: h'ainin~ for an Interact update synton for City of Ashland "Content Masters". This will
include e~',ablishing the detailed guideltnea for the in~rasiruoture, both hardware and sol'are4 and
the process by which the content is added, maintained, and supported_
Scope of Work
This project requires project A to perform several functions, including System Analysis, Design,
Development, Testing, Documentation, Deployment, and Training.
For more details about the scope of work for each area to be hnpzoved or developed, refer to the
attached Web Development Plan Phase One.
Deliverables and Milestones
There are four deliverables, which define the mile, stonea for lids project.
· The first deliverable will be the redesigned look and feel and navigation of the entire site to
facilitate dynamic content delivery me~h-~;sms.
· Thc second deliverable will be the integration of dlmnmlc llpdate tools into the site.
The third deliverable will be o~site trainin~ for "Content Masters" in the use of the tools to
update the site.
· The fourth deliverable will be the r~deployment of the ~ite to the major search engines and the
erection ~ pla¢inE of banner ads on lo~al sites with heav~ ~raffic.
Milestones
'fhe eatimated timeline for these four milestones is as follows. Thc first nfilestonc will be met within
forty-five (45) days after the ac, ceptan~e of these Projeet Specifications, and the recelpl of the deposit.
AU other milestones will be met within 45 days of the acceptance of the new look and feel. Since
completion of this project is timely a response to each deliverable is critical. City of Ashland agrees
tO provide a singlc point of contact to assist in the gathering, organization and layout of the new
content areas. Cit~ of Aslda~d also agr~a to provide a response to each deliverable wi:bin three
business days.
Spedalizin9 I. Ctmom G~ ~ - Iflmmet · I~mnet · Ac~ · VlsuM Irtk · W~om NT · Mulflm~lla" Nolvnxldng · Training -CAn~I!Ing sol~h~,~ 19';o.
SOFTWARE
SOLUTIONS
INTERNET
SOLUTIONS
vo~ $4T/4BS-1702
lex 541/498-1651
8O0/859.7639
Cily of Ashland - [~mamic lateme! Syslem Deve~apmeat
Project SpecificaUons
Costs
Thc total costs £or this projcct arc dependent on the total hours involved in peffo~i-g all o£the
functions necessary to complete the project, billed at ~ rate o1'$65 per hour. The total hours are
estimated to bo two hundred and twenty-five (225) hours. It is agreed that this project will not exceed
two hundred a~d twe~ty-fivc (21L~) hot~s or $14,625 without writtcn approval from City of Ashland,
The trams'of payment for these costs are as follows: A deposit equal to twenty five percent (25%) of
the estimated hours, or $3656, is required bofote work cc~r~eaces. A Purchase Order for the fifll
contract amount can be used in place of the deposit to initiate this contract. Actual hours, in quarter
hour increments, will be invoiced montkly. Invoices seut will first fully retire the deposit before any
additional balances w/il become due. All invoices are due within thirty (30) days. Invoices not paid
within thirty (30) days will be assessed a 1 ~ percent ~w~noe charge.
Agreement
We have carefully reviewed these specifications s,~4 agree to and accept thc terms and conditions.
Customer Con~ractor
By
Na~e --. Name
Title Title
Date Accepted
Date Accepted
SpecJoliz]ag in C~om C]ien~ Senec · hhmmet" In{mm - Aa~ · Yaaal Ba~£ · 1/fudaves ~ · MgtJrnedia · Nelex~ddng · Y~nlng oCdaflsd{i~ Sa~:{T{~,~4}~ 1990.
World ~ ~ Development ~ E~
Project A will propose, develop, imp[cmen~ msin~in ~d m~ag= ~c additions to ~e Interest site k~own as
~.~and.or. ua. P~J~t A will work closely ~ CiW pmonnei go ~her define a~ or development
and additions to ~e web site. ~e goal or~ls ~k is &e mleue of thc CiW web site for public usc on
World Wide Wcb.
Scope of Work
The silo will be brought to completion using the cnn'ant layout or "look and fc~l" and navigation tools.
Modifications will bc made to the site in aocordanoe with the feedback collected in meetings with City o1'
Ashhmd staff. The following areas will be addressed in this phase of'the project.
· Implementation of the dynamlG updam eels. · Events
· Meeting Agendas and Minutes
o . News Releases
· Employment
· Home page links
Deliverables
There is one deliverable for this task.
· Completion of development and posting o~' the web sim u~ P~ject A Servers in the v~v',v,ashland~r.us
domain.
Timeline
The estimated timeline for the projeot is a~ follows.
Development shaU begin immediately following the sigain8 ofthls agreement.
Release date for the complemd site is set for .Ta~uary
Costs
The total costs for development of this phase of the project are dependent on thc total hour~ involved in
p~:fforming all of the funotions ne~essar/to complain the project, billed at the rate of $65 per hour. The total
~.ours that is astimated for this phMc of project is two hundred and thirty (230) hours, It is agreed that this
project will not exceed two hundred ced thirty (230) hour~ or $14,950,00,
SOFTWARE
SOLUTIONS
INTERNET
SOLUTIONS
Agreement
We have carefully r~vicwed these specificatjon~ and agree to and accept the terms and conditions.
Date ^cocpted
I 1.16,9;~
Specializing in Custom Intrenat · Internet · Cllentl6erver~. Database · NT. VB · Ace®el Solutions Si~oe 1990
:OJECT A SHLAND
www.praJeGte.com
World Wide/Web Site~q~faining and Documet~tatlon
Task Definition
Project A will provide ~'aining end documentation for the use of the dynamic update tools known ss Active
Content. In addition do;umentation will be provided covering the entire tool Scl and their use. Also included
in this task will be deployment of the site to the search engines and planning for furore phases of thc project.
Scope of Work
This task requires Project A to perform several functi0us including Izroup training, documentation, on-site
training for individual Content Masters and support. In oddities this task includes deployment to nil of ibc major
search engines. The ful]owln~t areas will be addressed in both training and documentation this phase of ~he
project.
Implementation and training for the dynamic update tools.
· Meeting Agendas and Minutes
News Releases
· Emplo)nnent
· Home page links
· Planning and prioritizing the areas of lustre development.
· Training for CiO' Content Masers.
· Deployment of the site to Internal wide sea~c, h engines.
Deliverables
There are three deliverable~ at this stage of the project:
1. Deployment of the web site to search engb~e~ with 25 key words and an 80-word description.
2. Training in the use of the dynamic update tools.
3. Documentation of the reels and support for the Content Masters,
Timeline
The estimated timeline for the project is as follows.
Deployment of the site will be completed by Sanua,-y t 5,1999.
Training in the use of the tools is to be scheduled and completed no later that January I 5,1999.
Planning for the f~mre development of the site shall be ongoing.
Coal3
The total costs for development of this ph~e of the project are dependent on the total hours involved in
performing all of the functions necessary to complete the projeet, billed a: the rate of $65 per hour. The total
hours U~st is estimated for the oompletion of thin project Is seventy (70) hours, h is agreed that this project
not exceed seventy ('/0) hours Or $4,$50 without written approval ~rom Ci~ of AJhland.
Agreement
We have ~am~ully reviewed these sp~illcatlons and agree to mid accept Ibc lama and eondhions.
SOFTWARE Customer Contrectot~:7 . !
SOLUTIONS
iNTERNET B~~
SOLUTIONS N~e
Title
Date Aocepted
I I. 16/98
UJI L,;t
Hosting end Maintenance Specifications
CITY OF ASHLAND
World Wide Web Site
Hosting and Server Maintenance Specifications for 1998
prepaid by PmJ~et A.. JuLy 2s, 1~8
Task Definition
Project A will maintain and manage the additions to the [nterne~ site known as www.ashland.or.us.
Project A will store and maintain the contents of that site on servers connected to the Internal via a high
speed T-1 connection. This task shell be ongoing and the site will be monitored twenty-four hours a day
seven days a week.
Scope of Work
This task requires Project ^ to perform several functions, including importation and stem. go of da~.,
server monitoring, hardware maintenance, maintaining Imernet connectivity for the domain, beck up of
data. on-call personnel to respond if required. In addition Project A will pcrform upgrades and updates
to the web site as agreed upon by both panles.
Costs
Hostin§ and server maintenance services are offered at a flat rat~ of S250,00 per month. This figure is
ba.~-.,d on two hundred (200) megabytes of storage'~paee and 1000 megabytes of bandwldth to the site
per month, Additional storage will be tracked and bille4 quarterly et the rate of $1.25 pet me. byte pc*
month or $12.50 ~or every 10 megabytes. Additional bandwidth wlll be tracked end billed quarterly at
[h: ~[e o~$t 10 ~y megabyte per month or $50 for every 500 megabytes...amy additional maintenance
end/or development will be billed in quarter hour ineremee~ at $65 per hour and Invoiced monthly,
The terms of the payment for the, so costs are as follows: Three months of Hoqlng, Storage and
Maintenance servine payable et the time these Specifications ate a~capted, Invoices for additional throe-
month increments will automatically be sent during the final month of' esot three-month period, end ~dli
reflecl any chwages in the size et' storage space or bandwidth requited. The first three-month period will
be August I. 1908 through November 1, 1908, Either patty may terminate or modify this agreement
wilh thirty. [301 drys wrltten notice,
Total amount in,tinting this agreement is $750 payable on or within 10 days of'August I, 1998.
Agreement
We have carefully ravia,ced these speCifications and agree to and accept the terms and conditions.
[)ale Acecpled
Contractor/'/, /j . . /
Title ~
.....
Date ^c=epted
09/01 lug
· Ollant/gerYer a Database · NT · VB · Aoeeee Solutions Since 1990