HomeMy WebLinkAbout2003-217 Contract -Dunlap Contracting CITY OF ASHLAND
CONTRACT FOR PUBLIC WORKS CONSTRUCTION
Contract made this 2 c/wu day of
, between the City of Ashland, ("City") and Dunlap Contracting I,LC "(Contractor").
City and Contractor agree:
1. Contract Documents: This contract is made as a result of an Advertisement
for Bid issued by City for the Tolman Creek Road Improvement, Project Number 00-17.
Contractor was awarded thc bid as the lowest responsible bidder. In the event of any
inconsistencies in the terms of this contract, the contract documents defined in the
Advertisement for Bid and Contractor's bid, this contract shall take precedence over the
contract documents, which shall take precedence over the bid.
2. Scope: Contractor shall begin and complete the project described in the
contract documents within the time prescribed in the contract documents. Thc following
exceptions, alterations, or modifications to thc contract documents are incorporated into
this contract:
3. Price & Payment: City shall pay Contractor amounts earned undcr thc
contract. All payments will be made at the times and in thc manner provided in the
contract documents.
4. Bond: Contractor shall, within five days after exccution of the contract and
prior to doing any work under thc contract, furnish bond to the City of Ashland in a form
and with a surety satisfactory to City in the penal sum of $695,779.70 conditioned upon
the faithful performance of this contract upon the part of the Contractor.
Default: A dcfault shall occur under any of the following circumstances:
5.1 If the Contractor fails to begin the work under contract within the time
specified, or fails to perform the work with sufficient workers or
equipment or with sufficient materials to insure the prompt completion
of the project, or shall neglect or refase to remove materials or perform
anew such work as shall be rejected as defective or unsuitablc, or shall
discontinue the prosecution of the work.
5.2 If the Contractor shall become insolvent or declared bankrupt, or commit any act
of bankruptcy or insolvency, or allow any final .judgment to stand against the
Contractor unsatisfied for a period of forty-eight (48) hours, or shall make an
assignment for the benefit of creditors.
5.3 From any other cause whatsoever, shall not carry on the work in an acceptable
manner.
6. Remedies: In addition to the rights and remedies to which thc City may be
entitled by law for the enforcement of its rights under this contract, City shall have full
power and authority, without violating this contract, to take prosecution of the work l¥om
the Contractor, and appropriate or use any or all of the materials and equipment on the
ground that may be suitable and acceptable and may cause a contract for the completion
of this contract according to its terms and provisions, or use such methods as required for
the completion of the contract, in any acceptable manner. All costs m~d charges incurred
by the City together with the costs of completing the work under the contract, shall be
deducted from any money due or which shall become due the Contractor. In case the
expense so incurred by thc City shall bc less than the sum which would have been
payable under the contract if it had been completed by the Contractor, then the Contractor
shall be entitled to received the difl'erence less any damages for delay to which the City
may be entitled. In case such expense shall exceed the sum which would have been
payable under the contract, thc Contractor and thc surety shall be liable and agree to and
shall pay thc City the amount of the excess with damages for delay of performance, if
any.
7. Prevailin~ Wage Rates: The Contractor shall pay a fee equal to one-tenth of one
percent (0.1 percent) of price of this Contract. The fcc shall bc paid on or before the
first progress payment or 60 days from the date work first begins on the Contract,
whichever comcs first. Thc fcc is payable to the Bureau of Labor & Industries and
shall be mailed or otherwise delivered to the Bureau at the following address:
Bureau of Labor & Industries
Wage & Hour Division Prevailing Wage Unit
800 N.E. Oregon Street #32
Portland OR 97232
8. Living WaCe Rates: lfthe amount of this contract is $15,000 or mom,
Consultant is required to comply with chapter 3.12 of the Ashland Municipal Code by
paying a living wage, as defined in this chapter, to all employees performing work under
this contract and to any subcontractor who performs 50% or more of thc service work
under this contract. Consultant is also required to post thc attached notice predominantly
in areas whcrc it will bc sccn by all employees.
The Contractor shall fully comply with the provisions of ORS 279.348 through 279.365
pertaining to prevailing wage rates.
BY: G i-no~ri~m ald~
City Administrator
REVIEWED AS TO CONTENT:
D Date:
Coding:
(For City usc only)
PERFORMANCE & PAYMENT BOND
The undersigned DUNLAP CONq~RACrPING: r,r.C
. as principal, further
referred to in this bond as Contractor, and FIRST NATIONAL TN.qrlRAI'q~'~
COMPANY OF AMERICA , as surety, further referred to
in this bond as Surety, are jointly and severally bound unto City of Ashland, as obligee,
further referred to in this bond as City, in the sum Of~qlX ~i'[nxlnl~.n rqrtq,WTy W_TVE
THOUSAND SEVEN HUNDRED SEVENTY NINE DOLLARS & 70/100 .......
Dollars ($ 695,779.70 ).
Contractor and City have entered into a written contract dated 1 0 / 2 7 / 0 3
the following project: Tolman Creek Road Improvement Proiect No. 00-17. This
contract is further referred to in this bond as the Contract and is incorporated into this
bond by this reference.
The conditions of this bond are:
If Contractor faithfully performs the Contract within thc time prescribed
by the Contract, and promptly makes payment to all claimants, as defined
in ORS 279.526 through 279.542, then this obligation is null and void;
otherwise it shall remain in ~hll force and effcct.
If Contractor is declared by City to be in defanlt under the Contract, the
Surety shall promptly remedy thc default, perfbrm all of Contractor's
obligations under the contract in accordance with its terms and conditions
and pay to City all damages that arc due under the Contract.
3. This bond is subject to claims under ORS 279.526 through 279.542.
This obligation jointly and scverally binds Contractor and Surety and their
respective heirs, executors, administrators, successors.
Surety waives notice of modification of the Contract or extension of the
Contract time.
6. Nonpayment of the bond prcmium shall not invalidate this bond.
7. The bond number and the name, address, and telephone number of the
agent authorized to receive notices concerning this bond are as Ibllows.
Bond Number:
6197764
Bond Agent
Address:
Telephone:
MANSFIELD~ INC.
P.O. BOX 10327
PORTLAND, OR 97296-0327
(503)222-9971
MANSFIELD. INC.
.u.meo.OS;,.su
~- P.o. sox 'tga~,? ({
pOrMmhd, OR 97~7
(~) 2~-~7~ I F~: (503) ~
SIGNED this 27th
day of OCTOBER 2003.
WITNESS:
(Corporate Seal)
CONTRACTOR:By: ~ ~
Legal Address: Po BOX 1 951
Attest:
JACKSONVILLE, OR 97530
Corporate Sccretary
WITNESS:
(Corporate Seal)
SURETY: FIRST NATIONAL INSURANCE C~~F~
~IC~-- --= ---~
Title: MOLLY K:' ~NSFIELD/ATTO~eXEYkYh-~C2
LegalAddress: 4101 sw KRUSE WAY
LAKE OSWEGO, OR 97035
Attest:
CoriSorate Secr~ary
IMPORTANT NOTICE TO SURETY BOND CUSTOMERS REGARDING
THE TERRORISM RISK INSURANCE ACT OF 2002
As a surety bond customer of one of the SAFECO insurance companies (SAFECO Insurance Company of
America, General Insurance Company of America, First National Insurance Company, American States Insur-
ance Company or American Economy Insurance Company), it is our duty to notify you that the Terrorism Risk
Insurance Act of 2002 extends to "surety insurance". This means that under certain circumstances we may be
eligible for reimbursement of certain surety bond losses by the United States government under a formula
established by this Act.
Under this formula, the United States government pays 90% of losses caused by cerlified acts of terrorism that
exceed a statutorily established deductible to be paid by the insurance company providing the bond. The Act
also establishes a $100 billion cap for the total of all losses to be paid by all insurers for certified acts of
terrorism. Losses on some or all of your bonds may be subject to this cap.
This not~ce does not modify any of the existing terms and conditions of this bond, the underlying agreement
guaranteed by this bond, any statutes governing the terms of this bond or any generally applicable rules of law.
At this I~me there is no premium change resulting from this Act.
4333 l~;onklyn Avenue N.E.
Seattle, WA 98105
KNOW ALL BY THESE PRESENTS:
POW'ER
OF ATTORNEY
No. 4755
That FIRST NATIONAL INSURANCE COMPANY OF AMERICA, a Washington co~poration, does be,-eby aC:~onint
* ********************WILLIAM P. ~LMqSFIELD;, GEORGE A. MANSFIELD;, MOLLY K. MANSFIELD; MICHAEL $. MANSFIELD, Poo. taad, Oo~o*********************
its tm* and lawful attomey(s)-in-fact, with full authority to execute on behaif of Ih~ company f~er~ and eursty bonds or undertakings and ~Nher documents of a similar
character bsued by the c~:~npany In the oourse of ~s buslnaaa, and to bind FIRST NATIONAL INSURANCE COMPANY OF AMERICA thereby as fully as if such
IN WITNESS WHEREOF, FIRST NATIONAL INSURANCE COMPANY OF AMERICA has executed and attested these presents
R.A. PIERSON, SECRETARY
W. RANDALL STODDARD, PRESIDENT
CERTIFICATE
Extract from the Byq.aw~ of FIRST NATIONAL INSURANCE COMPANY OF AMERICA:
"A~lide V, Section 13. - FIDELITY AND SURETY BONDS ... the Pm~idon~ any Vk:e President, the Secmta~/, ~ amy Assistant Vice P~esident app<~nted for tha~
puqx~e by file off,::e~' irt charge of surer'/opefaltorts, shall each have authority to appoint Individuals as altomeys-in-fa~ or under o(her ap~-oprta~e title~ wilh authority to
execttta on behaif of the o:x~,oaz~y fx:ietEy and surety boc',ds and othe~' documonts of similar character issued by the company in t,he coume of its business... On any
instrument rns~ng or ev~::L-~ing suCh ap~3intmer~ the signatures may be ara(ed by facsimile. On any insltume~t confa~ng such authority or on any bond
unde~ttaking of the comoany, the seal, or a facsimile thereof, may be i~tpressed o¢' affixed o~ in any o¢hor manner reproduced; I:x'o~4a~ed, however, that the seal shall not
Extract from a Resotutkm of the Board of Directors of
FIRST NATIONAL INSURANCE COMPANY OF AMERICA adolXed July 25, 1970.
"On any certgcate exe<:t~d by the Secmtac/ar an assistant secxe{ary of the C~'npany setting ouL
(0 The provisions of Atticto V, Sedton 13 of ~he Byq.aws, and
(Il) ^ copy of t~he power-of-attorney apgoln~ ~ pursuant thereto, and
(i~} C.~ying if~at said power-of-attorney ap~Ym~e~t ts in fu~ fore and effect.
the signature of Ihe csfl~'ying offlcei' may ha by facsimile, and fha seal of the Compony may be a facsimite thoreof."
L R.A. Pi*lsat1, Seca~ar/of FIRST NATIONAL INSURANCE COMPANY OF AMER/CA, do hereby certify that the foregoing extracts of Ih* By4.awa and of a
Re~flution and Ih* Poe,~r of Ntome¥ am still in full fome and effect.
IN WITNESS WHEREOF, I ha'~ hemur~to set my hand and affixed Ih* facsimile seal of said coq)ora~on
SEAL
tK t928.,
R.A. PIERSON, SECRETARY
CORD . CERTIFICATE OF LIABILITY INSURANCE OATEIM ,yy,
10/27f2003
, PROOUCE~
MANSFIELD, INC.
, P.O. BOX 40327
PORTLAND, OR 97296~)327
503-222-9971 FAX: 503-221-3943
DUNLAP CONTRACTING, LLC
PO 8OX 1951
JACKSONVILLE, OR 97530
COVERAGES
Serial# B1335
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THiS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
INSURERS AFFORDING COVERAGE
,NSU~ER A ASSURANCE ~OMPANY
!Nsu~ 8 ASSURANCE COMPANY OF AMERICA
ff4SURER C
r NSURER E ASSURANCE COMPANY OF AMERICA
i A~'~ %(~lCtES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTAND NG
MAY QL~REMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TQ WHICH THIS CERT F CATE MAY BE rSSUED OR
po Li CP,~ 'AAA ~RE ~ ,~NT,~UL~MA~ T~Es~F[ O R D E D BY THE POLICIES DESCRIBED H~REIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF' SUCH
, WN MAY HAVE BEEN REDUCED BY P~D CLAIMS.
i COMM~RC~ALGENERALLIABILITY SCP 37809820
WA STOP GAP
pER P UECT '
: AUTOMO~LE. L~ABILITY i SCP 37809820
02/02/03
02/02/03
I DEDUC ,qSLE
OTHER
SCP 37809820 ~ 02/02/03
ANY & ALL OPERATIONS OF THE ABOVE NAMED INSURED
02/02104
02~02~04
EACHOCCURRENCE ; $ 1,000,000
FFFIRE DAMAGE (Any (~ne fir e)~$ 300!000
P~SONAL & ADVrNJURY I $ 1,000,000
~NER*~ AOeREO*~E ~ 2,000,0~8
PRODUCTS COMP~PAGG ::
02/02104
E~CH OCCURRENCE
AGGREGATE
$5,000 RENTED/LEASED
$1,000 DED
, THE CITY OF ASHLAND, T'S OFF CERS AGENTS & EMPLOYEES ARE NAMED AS AN ADDITIONAL INSUREDS WITH RESPECTS TO
THE ABOVE REFERENCED POLICIES,
RE: TOLMAH CREEK ROAD LOCAL IMPROVEMENT CONSTRUCTION PROJECT:#00-17
CERTIFICATE HOLDER i x ,!ADOTONAL N~RJFJ~ I~I~JF~)E~ LETTE~ X
CITY OF ASHLAND
20 E. MAIN STREET
ASHLAND, OR 9?520
CANCELLATION
Y~
ACORD 25,-S ~7/~7)
eACORr CORPORATION 1988
400 High St SE
Salem, OR 973~,2-1000
Toll Free 1-800-285-8525
OREGON WORKERS' COf4PENSAT/ON
CERTXFTCATE OF :XNSU RANCE
CER'rZFZCATE HOLDER:
C.[IY OF ASHLAND
ENGINEERING DEPARTMENT
20 E MAIN ST
ASHLAND, OR 97520
!he policy of insurance listed below has been issued to the insured named below for
he policy period indicated. The insurance afforded by the policy described herein is
ubject to all the terms, exclusions and conditions of such policy.
pOI ~Cy NO. POLICY PERIOD ISSUE DATE
907319 02/01/2003 TO 02/01/2004 10/29/2003
INSURED: BROKER OF RECORD:
DUNLAP CONTRACTING LLC
820 S OREGON ST
3ACKSONVILLE, OR 97530-9321
Bodily Injury by Accident $500,000 each accident
Bodily Injury by Disease $500,000 each employee
Bodily Injury by Disease $500,000 policy limit
TOLMAN CREEK ROAD IMPROVEMENT
Xf4PORTANT:
The coverage described above is in effect as of the issue date of this certificate. It is
subject to change at any time in the future.
This certificate is issued as a ma[tar of information only and confers no rights to the
certificate holder. This certificate does not amend, extend or alter the coverage
afforded by the policies above.
AUTHORIZED REPRESENTATIVE
CITY OF ASHLAND
20 E MAIN ST.
ASHLAND, OR 97520
(541) 488-5300
Cl'
'Y RECORDER'S COPY
Page 1 / 1
PO NUMBER
04660
VENDOR: 007981
DUNLAP CONTRACTING LLC
PO BOX 1951
JACKSONVILLE, OR 97530
FOB Point:
Terms: Net
Req. Del, Date:
Special Inst:
Descriptio
Tolamn Creek Road Improvements for
Local Improvement District, Proiect
00-17
BID
Date of contract: October 29, 2003
Contract start date: November 10, 2003
Completion date: June 30, 2004
Insurance required/On file
Street-260 08 12 00 704200 $45,000
LID- 260 08 17 00 704200 $240,000
St SDC -260 08 35 00 704200 $320,00(
Storm SDC -260 08 34 00 704200 $40
BILL TO: Account Payable
20 EAST MAIN ST
541-552-2028
ASHLAND, OR 97520
Account Number
E 260.08.12.00.704200
E 260,08.17.00.704200
E 260.08.34.00.704200
E 26008.35.00704200
00
Amount
45,000~30
240,000p0_
320,000~0
SHIP TO: Ashland Public Works
(541) 488-5587
27-1/2 N MAIN STREET
ASHLAND, OR 97520
Req. No.:
Dept.: PUBLIC WORKS
Contact: Pauta Brown
Confirming? NO
Unit Price Ext. Price
645,000.00
SUBTOTAL 645,000.00
TAX 0.00
FREIGHT 0.00
TOTAL 645,000.00
Account Number Amount
A u t h o r,r!~e"~n a t u r e
~ENDOR COPY
CiTY OF
, SHLAND
NOTICE OFTRANSMITTAL
TO:
KARl OLSON
DATE:
PROJECT:
JOB NO.:
SUBJECT:
NOVEMBER 13, 2003
TOLMAN CREEK RD IMPROVEMENT
00-17
CONTRACT
THE FOLLOWiNG ITEMS ARE BEING SENT TO YOU:
1. Original contract for the Tolman Creek Road Improvement Project No. 00-17
2. Requisition fbr purchase order
3. Original insurance certificates
4. Original bond forms
ENCLOSED X
UNDER SEPARATE COVER
REMARKS:
COPIES TO: Paula Brown
Department of PublicOk~o~
By: James H. Olson "~/~
Title: City Surveyor / };']tojb,~ Manager
PUBLIC WORKS
20 E. Main Street
Ashland, Ore on 97520
www.as~land.or, us
Tel: 541-488-5587
Fax: 541488-6006
TTY: 800-735-2900
G:\pub-wrks\engXdcpt admin ENGINEER/PROJEC'D2000x00 17 Olson Contract NOT doc
REQUISITION
CiTY OF
-ASI ILAND
No PW 322- FY 2004
Department Public Works
Vendor DUNLAP CON1RACIING LLC
PO BOX 1951
JACKSONVILI,E OR 97503
Accotmt No. Sec Below
Datc November 18, 2003
Requested Deli'~ery Date ASAP
DeliYer 1o PAULA BROWN
Via JIM OLSON
hnproven/cnt
Streetlund 260081200704200 $ 4~,00000
[.II) Pund 26008 I j/'00 704200 ~-
$
240,00000
Street SD( 260.083500704200 $ 320.00000
StormSDC 260.0834.00704200 $ 40.00000
TOTAL $ 64~000 00
fur Karl:
BID /RFP /EXEMPT: Bid
Contract Completion Date: June 30, 200d
Project No: 00-I 7
,lob No Unit No
/
Issued By Date Received B3
G Pubwrks/eng\deptadmin/engiaeer\project\00-17 Dunlap Requisition xls