HomeMy WebLinkAbout2004-176 Contract - Project ACITY OF ASHLAND
20 East Main Street
Ashland, Oregon 97520
Telephone: (541) 488-6002
FAX: (541) 488-5311
BEGINNING DATE: July I 2004
COMPENSATION: $95 per hour
(~ITY OF
SHLAND
PERSONAL SERVICES CONTRACT FOR SERVICES LESS THAN $25,000
CONSULTANT: ProjectA, Inc.
ADDRESS 340 A Street, Ashland, OR 9'/'520
TELEPHONE 541-488-1702
FAX: 541-488-1851
COMPLETION DATE: June 30 2005
SERVICES TO BE PROVIDED: ~Neb development .See attached addendum.
ADDITIONAL TERMS: See attached addendum.
CITY AND CONSULTANT AGREE:
1. All Costs by Consultant: Consultant slhall, at its own risk and expense, perform the personal services described above and, unless otherwise specified, furnish all labor,
equipment and materials required for the proper performance of such service.
2. Qualified Work: Consultant has represented, and by entering into this contract now represents, that all personnel assigned to the work requi~'ed under this contract are fully
qualified to perform the service to which they will be assigned in a skilled and workerlike manner and, if required to be registered, licensed or bonded by the State of Oregon, are
so registered, licensed and bonded.
3. Completion Date: Consultant shall start performing the service under this contract by the beginning date indicated above and complete the service by the completion date
indicated above.
4. Compensation: City shall pay Consultant for service performed, including costs and expenses, the sum specified above. Once work commences, invoices shall be prepared
and submitted by the tenth of the month for work completed in the prior month. Payments shall be made within 30 days of the date of the invoice. Should the contract be
prematurely terminated, payments will be made for work completed and accepted to date of termination.
5. Ownership of Documents: All documents prepared by Consultant pursuant to this contract shall be the property of City.
6. Statutory Requirements: ORS 279.312, 279.314, 279.316 and 279.320 are made part of this contract.
7. Living Wage Requirements: If the amount of this contract is $15,713 or more, Consultant is required to comply with chapter 3.12 of the Ashland Municipal Code by paying a
living wage, as defined in this chapter, to all employees performing work under this contract and to any subcontractor who performs 50% or more of the service work under this
contract. Consultant is also required to post the attached notice predominantly in areas where it will be seen by all employees.
8. Indemnification: Consultant agrees to defend, indemnify and save City, its officers, employees and agents harmless from any and all losses, claims, actions, costs,
expenses, judgments, subrogations, or other damages resulting from injury to any person (including injury resulting in death), or damage (including loss or destruction) to property,
of whatsoever nature arising out of or incident to the performance of this contract by Consultant (including but not limited to, Consultant's employees, agents, and others
designated by Consultant to perform work or services attendant to this contract). Consultant shall not be held responsible for any losses, expenses, claims, subrogations, actions,
costs, judgments, or other damages, directly, solely, and approximately caused by the negligence of City.
9. Termination: This contract may be terminated by City by giving ten days written notice to Consultant and may be terminated by Consultant should City fail substantially to
perform its obligations through no fault of Consultant.
10. Independent Contractor Status: Consultant is an independent contractor and not an employee of the City. Consultant shall have the complete responsibility for the
performance of this contract. Consultant shall provide workers' compensation coverage as required in ORS Ch 656 for all persons employed to perform work pursuant to this
contract. Consultant is a subject employer that will comply with ORS 656.017.
1110. Assignment and Subcontracts: Consultant shall not assign this contract or subcontract any portion of the work without the written consent of City. Any attempted
assignment or subcontract without written consent of City shall be void. Consultant shall be fully responsible for the acts or omissions of any assigns or subcontractors and of all
persons employed by them, and the approval by City of any assignment or subcontract shall not create any contractual relation between the assignee or subcontractor and City.
CON~L~ANT:
Or Social Security #
CITY OF ASHLAND:
BY
CITY ADMINISTRATOR
OR
.;FINANCE DI RE(?.,~OR
DATE: "?/Z.-'~/' ~g-
DATE: ",~/~,,/'.~/~C/.I'/TY D E PAJ:('I:M ~:I~IT HEAD
Accou. ' # )/0, /. 03. d d.
PURCHASE ORDER#
(for City purposes only)CITY OF ASHLAND PERSONAL SERVICES CONTRACT <$25,000 ~FORMS\contract for personal services)(rev'd 9/01)
7/1/2004
CITY' OF
- SHL, AND
Contract Definition
Project A will provide the City of Ashland with design, development, deployment and internal training for the content
provided on the Intemet site identified as www.ashland.or.us.
Scope of Work
All new content that arises lis a result of the development agreement will be imported and stored as part of the hosting
agreement. Import and storage costs will not be a part of any scope of work under the development agreement.
The development agreement will be conducted within separate and specific scopes of work that will adhere to the
following process:
The City, with input from Project A, will define a particular project or task.
Project A will provide an estimate of expected timeframe and costs associated with the task.
· Upon review and approval of the task estimates, an agreement will be signed to indicate a mutual understanding of
the work to be completed. All tasks agreements will adhere to all applicable sections of this contract.
Fee Structure
Word done within the framework of the development agreement will be billed on an hourly basis, at a rate of $95 per
hour. The number of hours billed for development will be based on the estimates provided in the individual task
agreements. The City understand that estimates are not considered firm agreements of the total development cost for
specific projects, and Project A will invoice for work completed on a "time and materials" basis. It is further
understood that Project A will not continue working on a project is the actual development time exceeds the estimated
development time without prior written approval from the City.
Billing
Invoices will be sent monthly and will be due 30 days from the invoice date. Past due amounts will be; assessed a 1.5%
penalty.
Contract Term
Either party has the right to terminate the contract at any time by giving a minimum of 60 days whtten notice in
advance of the contract ending date.
If the termination of the contract is initiated by Project A, an exit plan to enable future web development and hosting by
another firm must be submitted with the termination notice and be mutually agreed upon before the acceptance of the
termination. Fees for providing this exit plan will be charged as a development item.
It either party to this agreement wishes to amend, add to, or otherwise modify this agreement in any way, it shall be
done in writing, subject to approval by both parties, and attached to this agreement.
ADMINISTRATION Tel: 541488-6002
20 East Main Street Fax: 541-488-5311
Ashland, Oregon 97520 TD': 800-735-2900
www.ashland.or, us
City of Ashland
LIVING
WAGE
~per hour effective June 30, 2004
(Increases annually every Jur, e 30 by the
Consumer Price Index)
For all hours workecl under a
service contract between their
employer and the City of
Ashland if the contract
exceeds $15,964 or more,
For all hours worked in a
month if the employee
spends 50% or more of the
employee's time in that month
working on a project or portion of
business of their employer, if the
employer has ten or more
employees, and has received
financial assistance for the project
or business from the City of
Ashland in excess of $15,964.
If their employer is the City of
Ashland including the Parks
and Recreation Department.
In calculating the living wage,
employers may add the value of
health care, retirement, 401K and
IRS eligible cafeteria plans
(including childcare)benefits to
the amount of wages received by
the employee.
Call the Ashland City Administrator's office at 541-488-6002 or write to the City Administrator,
City Hall, 20 East Main Street, Ashland, OR 97520 or visit the city's website at vvww.ashland.or.us.
Notice to Employers: This notice must be posted predominantly in areas where it will be seen by all employees.
CITY OF
-AS H LAN D
bAlD uorporation ~lZil',,'.ou~
400 High St SE
Salem, OR 97312-1000
Toll Free 1-800-285-.8525
OREGON WORKERS' COMPENSATION
CERTIFICATE OF INSURANCE
~ERT/FTCATE HOLIDER:
.iThe policy of insurance listed below has been issued to the insured named below for
the policy period indicated. The insurance afforded by the policy described herein is
tsubject to all the terms, exclusions and conditions of such policy.
POLICY NO, POLICY PERIOD ISSUE DATE
623491 04/01/2004 TO 04/01/2005 04/21/2004 .
INSURED:
PRO]ECT A INC
340ASTSTE 1
ASHLAND, OR 97520-1962
BROKER OF RECORD:
SECUR1TY INSURANCE, A ]BL&K
COMPANY
707 MURPHY ROAD
MEDFORD, OR 97504
LIMITS OF LIABILITY:
Bodily Injury by Accident $500,000 each accident
Bodily Injury by Disease $500,000 each employee
Bodily Injury by Disease $500,000 policy limit
DESCRIPTION OF OPERATIONS/LOCATIONS/SPECIAL ITEMS:
ALL OPERATIONS.
IMPORTANT:
The coverage described above is in effect as of the issue date of this certificate. It is
subject to change at any time in the future.
This certificate is issued as a matter of information only and confers no rights to the
certificate holder. This certificate does not amend, extend or alter the coverage
afforded by the policies above.
AUTHORIZED REPRESENTATIVE
Client: 10118 PROJEC1
J DATE (MM/DD/YYYY/
ACORD, CERTIFICATE OF LIABILITY INSURANCE
PRODUCER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
Insurehitech ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
100 Village Blvd Suite 200 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
Princeton, NJ 08540-7104
609 987-0221 INSURERS AFFORDING COVERAGE NAIC #
INSURED INSURER A: St'. Paul Fire & Marine
Project A, Inc. INSURER B:
340 A Street, Building 1 INSURERC
Ashland, OR 97520 INSURER D:
INSURER E:
COVERAGES
, -
-
--- -
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING
ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN, THE INSURANCE AFFC)RDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS.
'' ~ S ~I ADD'L POLICY EFFECTIVEPOLICY EXPIRATION
LTR INSRE TYPE OF INSURANCE POLICY NUMBER DATE IMM/DD/YY) DATE (MM/DD/.YY) ,, LIMITS
A GENERAL LIABILITY VP06301136 12/16/03 12/16/04 EACH OCCURRENCE $1,000,000
-- DAMAGE TO RE'NTFD
X COMMERCIAL GENERAL LIABILITY PREMISES (La o¢currencel $250,000
CLAIMS MADE ~] OCCUR MED EXP (Any one person!, i $10,000
-- PERSONAL & ADV INJURY s1,000,000,
GENERAL AGGREGATE s2~000~000
GEN'L AGGREGATE LIMIT APPLIES PER: PRODUCTS - COMP/OP AGG s2,,000,000
.....
FF
A AUTOMOBILE LIABILITY VP06301136 12/16/03 12/16/04 COMBINED S~NGLE UM~T
I ANY AUTO (La accident) $1,000,000
ALL OWNED AUTOS BODILY INJURY $
SCHEDULED AUTOS (Per person/
X HIRED AUTOS BODILY INJURY $
X NON-OWNED AUTOS (Per accident)
PROPERTY DAMAGE $
(Per accident)
GARAGE LIABILITY AUTO ONLY EA ACCIDENT $
t ANY AuTO OTHER THAN EA ACC
AUTO ONLY AGG $
IOCCUR ~ CLAIMS MADE AGGREGATE
$
DEDUCTIBLE $
RETENTION $ $
I wc STATU- I OTH-
WORKERS COMPENSATION AND TORY LIMITS ER
EMPLOYERS' LIABILITY
E.L EACH ACCIDENT
ANY PROPRIETOR/PARTNER/EXECUTiVE
OFFICER/MEMBER EXCLUDED? E,L. DISEASE - EA EMPLOYEE $
If yes, describe under
SPECIAL PROVISIONS belqw E L, DISEASE - POLICY LIMIT $
OTHER
DESCRIPTION of OPERATIONS / LOCATIONS / VEHICLES / EXCLUSIONS ADDED BY ENDORSEMENT / SPECIAL PROVISIONS
CERTIFICATE HOLDER
CANCELLATION
SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXt:'~RATION
DATE THEREOF, THE ISSUING INSURER WILL ENDEAVOR TO MAIL ."{{") DAYS WRITTEN
NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT FAILURE TO DO SO SHALL
IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON T-iL INSURER, ITS AGENTS OR
i REPRESENTATIVES.
AUTHORIZED REPRESENTATIVE
,,,t:%
SEC
ACORD 25 (2001/08) 1 of 2 #S17603/M16470 o ACORD CORPORATION 1988
REQUISITION FORM
THIS REQUEST IS A:
J~]~C~hange Order(existing PO # ___
Vendor Name:
Address:
City, State, Zip:
Phone:
Fax Number
Deliver Location
C, ITY OF
,ASHLAND
Date of Request: I~/~,,//~' I
Required Date of Delivery/Service:
Services Only
Description Total Cost Solicitation Process:
J--J Exempt ~ 3 WriRen Quotes
(copies attached)
~ole Source ~ Invitation to Bid
(copies on file)
~ Less than ~ Request for
$5000 Proposal (copies on file)
Account Number _~./~- ~ J-¢~,t._~--~ P~/z.g
*Please attach the Original signed contract ~,'n-d Insurance certificate,
Materials Only
Item # Quantity Unit Description Unit Cost Total Cost
Account Number~ ...... - ........... - ............ - ..............................
*P/ease attach the quotes.
Employee Signature: ~ SupervisoflDept. Head Signature: ~-~,~
NOTE: By signing this requisiti'~; form,; ce~'fy that th~bove request meets the City of Ash/and Solicitation Process requirements and can t~/ovided
when necessary.
G:Finance\Procedure~AP\Forms\8_Requisition form.doc Updated on:07/15/02
CITY OF ASHLAND
20 E MAIN ST.
ASHLAND, OR 97520
(541 ) 488-5300
CITY RECORDER'S COPY
DATE [
7/29/2004
Page 1 / 1
f" ':""PO"NUMBER: ":'t
05291
VENDOR: 000712
PROJECT A, INC
340 A STREET
ASHLAND, OR 97520
SHIP TO: City of Ashland
(541 ) 488-6002
20 E MAIN STREET
ASHLAND, OR 97520
FOB Point:
Terms: Net 30 days
Req. Del. Date: 7/1/2004
Special Inst:
Req. No.:
Dept.: ADMINISTRATION
Contact: Ann Seltzer
Confirming? NO
BLANKET PURCHASE ORDER
· ... ::' :..= .... .~.:.:..:.........: ..::.: : :.:.. . .:WebDevel.oprnent.=~.? . .. ?: ..::. ...:. .... / . .:. :::..:..:....:...............:..............:...................:............~..:i~iI .i .': :i :'': .i :. ~.i ~i iI :.i:i.: ! 151000,001.11
$95.00 per hour ........
: .. :..: ...:.' ...'.:.'.':":.:::i...::::....~":. '.":.i;.':':i:::~ . ?':':'...". ;".:~bt:"..'t0,.ie:~c~e:d.::...$'5;00'o:i.....:'.:.:.:.~'::.::':.'.::..."....".: "..:::..'i:'.'..'."..".:'::i':":.:'...".':'":.: :'.."..' .'..: .'.:' .'.::'.: '.:":" i.'"i.. :..'..::...':;..:':..:'...' :.. i.'...". ':. ".'..:'..=' .'"i.'i.:'. · i..i~ .' "..'. · · "...'..' '.= .. =..'. ."..'."....' "':" .'''''=: '.'..."".
PSK
Beginning date: July 1, 2004
·
Completion date: June 30, 2005
I
,
SUBTOTAL 5,000.00
BILL TO: Account Payable TAX 0.00
20 EAST MAIN ST FREIGHT 0.00
541-552-2028 TOTAL 5,000.00
ASHLAND, OR 97520
Account NUmber Amount Account Number Amount I
E 710.01.02.00.604100 5,000.00
.
\/~:1~1"1C1~ ~.("IPY