HomeMy WebLinkAbout2005-298 Contract - R&G Excavating
CITY OF ASHLAND
CONTRACT FOR PUBLIC WORKS CONSTRUCTION
Contractmadethis Oc.t~)~02{,t1\ dayof~hk/' ,2005,
between the City of Ashland, ("City") and R&G Excavating Inc. "(Contractor").
City and Contractor agree:
1. Contract Documents: This contract is made as a result of an Advertisement
for Bid issued by City for the Water Treatment Plant Filter Upgrades. Contractor was
awarded the bid as the lowest responsible bidder. In the event of any inconsistencies in
the terms of this contract, the contract documents defined in the Advertisement D)r Bid
and Contractor's bid, this contract shall take precedence over the contract documents,
which shall take precedence over the bid.
2. Scope: Contractor shall begin and complete the project described in the
contract documents within the time prescribed in the contract documents. The following
exceptions, alterations, or modifications to the contract documents are incorporated into
this contract: No alterations to bid specifications.
3. Price & Payment: City shall pay Contractor amounts earned under the
contract. All payments will be made at the times and in the manner provided in the
contract documents.
4. Bond: Contractor shall, within five days after execution of the contract and
prior to doing any work under the contract, furnish bond to the City of Ashland in a form
and with a surety satisfactory to City in the penal sum of $118,060.00 conditioned upon
the faithful performance of this contract upon the part of the Contractor.
5. Default: A default shall occur under any of the following circumstances:
5.1 If the Contractor fails to begin the work under contract within the time
specified, or fails to perform the work with sufficient workers or
equipment or with sufficient materials to insure the prompt completion
of the project, or shall neglect or refuse to remove materials or perform
anew such work as shall be rejected as defective or unsuitable:, or shall
discontinue the prosecution of the work.
5.2 If the Contractor shall become insolvent or declared bankrupt, or commit any act
of bankruptcy or insolvency, or allow any final judgment to stand against the
Contractor unsatisfied for a period of forty-eight (48) hours, or shall make an
assignment for the benefit of creditors.
5.3 From any other cause whatsoever, shall not carryon the work in an acceptable
manner.
6. Remedies: In addition to the rights and remedies to which the City may be
entitled by law for the enforcement of its rights under this contract, City shall have full
power and authority, without violating this contract, to take prosecution of the work from
the Contractor, and appropriate or use any or all of the materials and equipment on the
ground that may be suitable and acceptable and may cause a contract for the completion
of this contract according to its terms and provisions, or use such methods as required for
the completion of the contract, in any acceptable manner. All costs and charges incurred
by the City together with the costs of completing the work under the contract, shall be
deducted from any money due or which shall become due the Contractor. In case the
expense so incurred by the City shall be less than the sum which would have been
payable under the contract if it had been completed by the Contractor, then the Contractor
shall be entitled to received the difference less any damages for delay to which the City
may be entitled. In case such expense shall exceed the sum which would have been
payable under the contract, the Contractor and the surety shall be liable and agree to and
shall pay the City the amount of the excess with damages for delay of performance, if
any.
7. Prevailing Wage Rates: The Contractor shall pay a fee equal to one-tenth of one
percent (0.1 percent) of price of this Contract. The fee shall be paid on or before the
first progress payment or 60 days from the date work first begins on the Contract,
whichever comes first. The fee is payable to the Bureau of Labor & Industries and
shall be mailed or otherwise delivered to the Bureau at the following address:
Bureau of Labor & Industries
Wage & Hour Division Prevailing Wage Unit
800 N.E. Oregon Street #32
Portland OR 97232
8. Living Wage Rates: If the amount of this contract is $15,000 or more,
Consultant is required to comply with chapter 3.12 ofthe Ashland Municipal Code by
paying a living wage, as defined in this chapter, to all employees performing work under
this contract and to any subcontractor who performs 50% or more of the service work
under this contract. Consultant is also required to post the attached notice predominantly
in areas where it will be seen by all employees.
The Contractor shall fully comply with the provisions ofORS 279.348 through 279.365
pertaining to prevailing wage rates.
Its:
1iu'trpJ.--
CITY OF,I1H LAND 'I / J-
By: ~- ~I
Gino Grimaldi
City Administrator
CONTRA" , CT?R/3v6" /
Il/; fll/ _ i', I)
By: 'f~ . ~ .
REVIEWED AS TO CONTENT:
By: ~V#
Dep ment Head Date: J [! '.?;.
Coding: V ~" IY~ / '1 tp '7 ~ ;;L ttP 0
(For City use only)
?? t?~~~'1
f. f (J
------
Certificate of Insurance
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE
IS NOT AN INSURANCE POLICY AND OOES NOT AMEND, EXTEND, OR ALTER THE COVERAGE AFFORDED BY THE POLICIES LISTED.
This is to Certi fy that
~ Liberty
\P1' Northwest@
R & G. EXCAVATING INC.
39300 MONTGOMERY DR
SCIO OR 97374-9530
11.1..1...1..11.1...1.1..11.1...1.1...11.11...11...11.....11.1
Member of Liberty Mutual Group
PO Box 4555
Portland, OR 97208-4555
503.239.5800
is, M the riMe of the c"rtificate. insured by the Company under the policy(;esl listed below. The insurance afforded by the listed policY!ies)
is subject to all their terms, exclusions, and conditions and is not altered by any requirement, term or condition of any contract or other
document with respect to which this certificate maybe issued.
TYPE OF POLICY EXPIRATION POLICY NUMBER LIMITS OF LIABILITY
DATE
COVERAGE AFFORDED UNDER W.e. LAW COVERAGE AFFORDED UNDER W.e. LAW
OF FOLLOWING STATES: OF THE FOLLOWING STATES:
IX! WORKERS'
COMPENSA TlON 1 % 1 /2006 WC4-1 NC-006867 OR
EMPLOYERS LIABILITY LIMITS EMPLOYER LIABILITY LIMITS
Each accident S 500,000 Each accident S
Disease - policy limit S 500,000 Disease - policy limil $
Disease - each employee S 500,000 Disease - each employee S
MARITIME COVERAGE-FOLLOWING STATES LIMIT OF lIAB.-MARITIME COVERAGE
GENERAL LIABILITY General Aggregate S
0 Products Comp/OPS Aggregate S
Commercial General
Liabilily (Occurence) Personal & Advertising Injury S
0 Owner's and Each Occurence S
Contractor's Protective Fire Damage (Anyone lire) S
0 Medical Expense (Anyone person) S
AUTOMOBILE LIABILITY
0 Any Auto CSL S
0 All owned Autos Bodily Injury (Per Person) S
0 Scheduled At:!3~ Bfld!!y In]llr~J (P~r Acr:ident) S
0 Hired Autos Property Damage S
0 Non-owned Autos
0 Garage liability
0
OTHER
LOCATlON(S} OF OPERATIONS & JOB # OF APPLICABLE) DESCRIPTION OF OPERATIONS
WATER TREATMENT PLANT FILTER UPGRADES, FAX & MAIL CH
PROJECT 04-11 FOR THE CITY OF ASHLAND CH FAX:541-488-6006
SHOULO ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, THE ISSUING
CANCELLATION: COMPANY WILL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED BELOW. BUT
FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE COMPANY. OR
REPRESENTATIVES,
MAILED TO: I
CITY OF ASHLAND / ~
ENGINEERING
20 . ~ AUTHORIZED REPRESENTATIVE
E MAIN ST
ASHLAND OR 97520-1850
11.1..1...1.1.1...1.111......111..1..1.1.11...1.1..1.1...1.1.1
EFS Ih
9/28/2005 SALEM
DATE ISSUED
OFFICE
Page 1 / 1
r~'
ASHLAND/TY RECORD~ . ~
20 E MAIN ST. .~ L 06467 ~
ASHLAND, OR 97520
(541) 488-5300
VENDOR: 009545
R & G EXCAVATING INC
39300 MONTGOMERY DRIVE
SCIO, OR 97374
SHIP TO: Ashland Public Works
(541) 488-5587
51 WINBURN WAY
ASHLAND, OR 97520
FOB Point:
Terms: Net
Req. Del. Date: 11 /1 /2005
Speclallnst:
Req. No.:
Dept.: PUBLIC WORKS
Contact: Pieter Smeenk
Confirming? No
THIS IS A REVISED PURCHASE ORDER
BLANKET PURCHASE ORDER
Two filter upQrades at the Water
Treatment Plant with an option to
complete two more filters next fiscal
year. ERS Industrial is the project
enQineer.
118,060.00
BID
Contract start date: November 1, 2005
Contract completion date: January 2006
Insurance required/On file
BILL TO: Account Payable
20 EAST MAIN ST
541-552-2028
ASHLAND, OR 97520
SUE!ITOTAL
TAX
FBEIGHT
TOTAL
118
~ ~~_.-"~ . ~Y~J
Author Signature
VENDOR COPY
CITY OF
ASHL)\.ND
PROJECT ACCOUNTING WORKSHEET
PROJECT NUMBER (YEAR XX)
PROJECT TITLE
2004111
IWATER TREATMENT PLANT FILTER UPGRADES
PROJECT DESCRIPTION
Department
Project Manager
Department Head
BUDGET INFORMATION
Identify fiscal year I potential splits
Identify Funding Codes
and Funding Code names
DESIGN .100
Engineer Name
PO
COST
Change Orders 1
2
3
4
CONSTRUCTION .120
contractor name
PO
budget estimate
bid I contract total
changes
total
CONSTRUCTION MANAGEMENT .150
engineer name
PO
budget estimate
bid I contract total
changes
total
PERMIT COSTS (Building Dept) .170
budget estimate
final costs
Replacement of filter media at the Water Treatment Plant to accomplish higher water production
I
Public Works - Water Supply
Pieter Smeenk (Ed Olson)
Paula Brown
IFY05
IFY06
I
I
I
~
670.08.19.00.704200
There is an option to complete two more filters at $246,060 within
the next year.
~/3for
Water Treatment Plant Contracted Proiects
ERS Industrial
4851
$ 34,714.28
$ 34,199.24
$ 15,285.16
$ 8,485.20
$ 9,557.04
$ 102,240.92
R&G Excavating
Pending
$ 118,060.00
$ 118,060.00
~7
INauJ1 jlt-
/1 ~/)AJl ~ Y
/\
G:PUlw<<ksle\loldept-admi",engineer~ecllCI4-11 Proj AccI Worksheel.x1s
CITY OF
ASHLAN[)
REQUISITION
No. PW - FY 2005
Department PUBLIC WORKS
Vendor R&G EXCAVATING INC.
39300 MONTGOMERY DRIVE
SCIO OR 97374
Account No. 670.08.19.00.704200
Date November 11,2005
Requested Delivery Date
Deliver To Dawn Lamb
Via
ASAP
(. Note: Please allow approximately two(2) weeks for delivery on items not
generally caried in stored, and approximately two (2) months on printing jobs.)
Item No. Quantity
Unit
Description
Use of Purchasing Office Only
Unit Price Total Price PO No.
Two filter upgrades at the Water Treatment Plant
with an option to complete two more filters
next fiscal year. ERS Industrial is the project S 118,060.00
engineer.
TOTAL $ 118,060.00
NO
Job No.
Unit No.
'-, .............;- ~......., "'.. -~~
~..._,..~....... 2,.
, Department Head or Authe,rized Person
Issued By
Date
Received By
~~
G:Pub-wrksleng/dept-admin/engineer/projectlG:\pub-wrkslengldept-adminIENGINEERIPROJECTI2003\04-11 RG Requisition 11 OS.xls