HomeMy WebLinkAbout2006-062 CONT Chg Order #1 - Weathers Crushing
~~,
Page 1 / 1
CITY OF
ASHLAND
20 E MAIN ST.
ASHLAND,OR 97520
(541) 488-5300
DATE
5/25/2006
PO NUMBER
06823
VENDOR: 006544
WEATHERS CRUSHING INC
6070 ROCK WAY
CENTRAL POINT, OR 97502
FOB Point:
Terms: Net
Req. Del. Date: 5/10/2006
Speciallnst:
SHIP TO: Ashland Public Works
(541) 488-5587
51 WINBURN WAY
ASHLAND, OR 97520
Req. No.:
Dept.: PUBLIC WORKS
Contact: Jim Olson
Confirming? No
Quantity Unit DescriDtion Unit Price Ext. Price
THIS IS A REVISED PURCHASE ORDER
BLANKET PURCHASE ORDER
CrushinQ 3077 cubic yards of asphalt at 24,000.00
the Granite Street pit.
RFQ
BeQinninQ date: May 10, 2006
Completion date: June 10, 2006
Insurance required/On file
ChanQe Order No 1 4,998.00
Opportunity for additional crushinQ
*** This is a chanQe order. ***
SUBTOTAL 28 998.00
BILL TO: Account Payable TAX 0.00
20 EAST MAIN ST FREIGHT 0.00
541-552-2028 TOTAL 28,998.00
ASHLAND, OR 97520
Account Number Project Number Amount Account Number Project Number Amount
E 260.08.12.00.60240( 28 998.00
~ ~-Sign~~--4
VENDOR COpy
A request for a Purchase Order
REQUISTION FORM
CITY OF
ASHLAND
Date of Request:
THIS IS A REQUEST FOR A:
[XXI Change Order (e~sting p~ t7 Vt? ~ g
Required Date of Delivery/Service:_
Vendor Name:
Address:
City, State, Zip
Phone:
Project Title:
Project Number:
WEATHERS CRUSHING INC.
6070 ROCK WAY
CENTRAL POINT OR 97502
664-4360
2006 ASPHALT CRUSHING
N/A
[ ]
Services Only
*Only one bid received in response to advertisement.
[ 1 ~empt .
[ ] Less than $5000
Description
Total Cost
Opportunity for additional crushing.
Asphalt crushing at the granite pit.
Change Order No.2
Account Number
260.08.12.00.602400
"Please attach the Original signed contract and Insurance Cettificates.
Account Number
Employee Signature: Supervisorl Depl Head Signature:
NOTE: By signing /his requistiion fonn, I certify /ha the above request meets with Ctiy of Ashland Solicitiation Process require
G: Pubwrl<slEngl2006 AsphaK Crushing CO 1 7 06.xls
Updated on: 7/15102
Page 1 /1
r~'
.C I T Y ~lifY RECORDER'S COpy
ASHLAND ~
20 E MAIN ST. 5/25/2006
ASHLAND, OR 97520
{541} 488-5300
I r
06823
VENDOR: 006544
WEATHERS CRUSHING INC
6070 ROCK WAY
CENTRAL POINT, OR 97502
SHIP TO: Ashland Public Works
(541) 488-5587
51 WINBURN WAY
ASHLAND, OR 97520
FOB Point:
Tenns: Net
Req. Del. Date: 5/10/2006
Speciallnst:
Req. No.:
Depl: PUBLIC WORKS
Contact: Jim Olson
Confinning? No
BLANKET PURCHASE ORDER
CrushinQ 3077 cubic yards of asphalt at
the Granite Street pit.
24,000.00
RFQ
BeQinninQ date: May 10, 2006
Completion date: June 10, 2006
Insurance reQuired/On file
BILL TO: Account Payable
20 EAST MAIN ST
541-552-2028
ASHLAND, OR 97520
SUBTOTAL
TAX
FREIGHT
TOTAL
24
~ .-1v-- --fua- ~J/~L
Au Zed Signature
VENDOR COPY
. .<:... l'J''Y . .~..:f' ........
A.............S......................N................ ......1..,. ..... A...... ... N. ....................[)....... m
.. . ,....... ........ ,--P..." ,. '" "" ..
. ". ...,..
. .... ..... .
. . ,... . .
..... "'......-- ,-. ,,-,.. . ......,. . "".. ...-.- ..---.-.
o ." , , '. ' , , .
..."",... u.. .",,,. . .. ,,,..
...... ... ...... .......m . . ...m . ....... ..... ..... .. .... ............
REQUISITION
No. PW - FY 2006
Department Street Department
Vendor WEATHERS CRUSHING INC.
6070 ROCK WAY
CENTRAL POINT OR 97502
Account No. 260.08.12.00.602400
Date May 23, 2006
Requested Delivery Date
Deliver To
Via
(. Note: PI.... oIJow ~ t\W(2) woob lOr deIiwIy... items DOt
P*ODY cariod in SlOred, ond opproximllolytwo (2) 1IIIlIIlhs... priDlingjobs.)
ASAP
JOHN PETERSON
Item No. Quantity
Unit
Description
Crushing 3077 cubic yards of asphalt at the Granite
Street pit
$ 24,000.00
TOTAL
S 24,000.00
Job No.
Unit No.
~-==:::::-1:- UtJL-.
~HeodorA__
Issued By
Date
Received By
~;.,
G:Pubwr1la\engldeptadmln\engr-\projectl2006 Asphalt Crushing Weathers Requlsillon 506.x1s
- -------..,-
ACORD.. CERTIFICATE OF LIABILITY INSURANCE I DATE(MMlDDlYYYY)
5/9/2006
PRODUCER (541) 772-1111 FAX (541.) 772-3785 THIS CERTIFICA'IE IS ISSUED AS A MATTER OF INFORMAnON
Security Insurance ONLY AND CONFERS NO RIGHTS UPON THE CERnFICATE
HOLDER. THIS CERnFICATE DOES NOT AMEND, EXTEND OR
707 Murphy Road. ALTER THE COVERAGE AFFORDED BY THE POUCIES BELOW.
Medford OR 97504 INSURERS AFFORDING COVERAGE NAIC#
INSURED INSURER A:. Orecton Aut:omobi~e Ins Co 23922
Weat:hers Crushinq Ine INSURER B:
6070 Rock Way INSURER C:
INSURER D:
Cent:ru Point: OR 97502 INSURER E:
COVERAGES
THE POlICIES OF INSURANCE USTED BELOVI/ HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POliCY PERIOD INDICATED. NOlWlTHSTANDlNG ANY
REQUIREMENT, TERM OR CONDITlON OF ANY CONTRACT OR OTHER Dcx::UMENT WITH RESPECT TO \MilCH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,
THE INSURANCE AFFORDED BY THE POUCtES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POUCIES.
AGGREGATE LIMITS SHOIMIl MAY HAVE BEEN REDUCED BY PAID CLAIMS.
INSR ADD'L POLICY EFFECTIVE POLICY EXPIRATION UMITS
LTR NSRD TYPE OF INSURANCE POLICY NUMBER DATE (MMIDDIYY) DATE
.!.,.ENERAL LIABILITY EACH OCCURRENCE S 1,000,000
~ ::~rMERClAL GENERAl LIABILITY ~~~~9.:~=......, S 100,000
A - CLAIMS MADE [!] OCCUR C161124!59 9/1/2005 9/1/2006 MED EXP {Any one_I S 5,000
PERSONAL & ADV INJURY S 1,000,000
GENERAL AGGREGATE S 2,000,000
~N'LAGG~nLIMIT AnSPER: PRODUCTS - COMPIOP AGG S 2,000,000
X POUCY ~g: LOC
~UTOMOBlLE UABILITY COMBINED SINGLE UMIT S 1,000,000
~ /W'( AUTO lEa accIdenll
A - ALL OINNED AUTOS C161124!59 9/1/2005 9/1/2006 BODILY INJURY
(Per person) s
- SCHEDULED AUTOS
- I-lIRFn AUTOS SOOlL Y INJURY S
NON-O'llNED AUTOS (Per accident)
-
PROPERTY DAMAGE S
(Per accidentl
~RAGE UABlLITY AUTO ONLY - EA ACCIDENT S
AHYAUTO OTHER THAN EANX S
AUTO ONLY: AGG S
EXCEl5MJMIlRELLA LIABlUTY EACH OCCURRENCE S
:=J OCCUR 0 CLAIMS MADE AGGREGATE S
S
~ DEDUCTIBLE S
RETENTION S S
WORKERS COMPENSATION AND I TORY UMlTS I lON
EMPLOYERS' UABlUTY
ANY PROPRIETORlPARTNER/EXECUTIVE E.L. EACH ACCIDENT S
OFFICERlMEMBER EXCLUDED? E.L. DISEASE. EA EMPLOYR= S
If yes, desaibe LIlder E.L. DISEASE - POUCY LIMIT S
SPECIAL PROVISIONS below
OTHER
DESCRIPTION OF OPERATIONSlLOCATIONSNalICLESlEXCLUSIONS ADDED BY ENDORSEMENTISPECIAL PROVISIONS
Re: Asphalt crushing. Verirication or insuranoe. SUbject to policy terms, conditions and exclusiona.
CERnFICATE HOLDER CANCELLAnON
SHOULD ANY OF THE ABOVE DESCRIIlB) POUClES BE CANCELLED BEFORE THE
Ci t:y of Ash~and EXPIRATION DATE THEREOF, THE ISSlJING IlSURER WILL ENDEAVOR TO MAlL
Dawn Lamb 10 DAYS WRITTBI NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT, BUT
Iti..k Kanageu.nt Dept. -
20 East: Main FAILURE TO DO so SHALL IMPOSE NO OBLIGATION OR UABlLITY OF ANY KIND UPON THE
As~and, OR 97520 INSlJRER ITS AGENTS OR REPRESENTATIVES.
AUTHORIZED REPRESENTATIVE ::::;-'-_ ~. W~
Susan Wilson, MI,
ACORD 211 (2001108)
INS0211 (0108).08 AMS
VMP Mortgage SoI.mons, Inc. (800)327-0545
e ACORD CORPORAnON 1888
Page 1012
CITY OF ASHLAND
CONTRACT FOR PUBLIC WORKS CONSTRUCTION
Contract made this ) C
Ashland, ("City") and
day of 11AA1 ,1odt. , between the City of
Weathers CrushinQ Incorporated "(Contractor").
City and Contractor agree:
1. Contract Documents: This contract is made as a result of an Advertisement
for Bid issued by City for the Asphalt Crushing in the Granite Street Yard. Contractor
was awarded the bid as the lowest responsible bidder. In the event of any
inconsistencies in the terms of this contract, the contract documents defined in the
Advertisement for Bid and Contractor's bid, this contract shall take precedence over the
contract documents which shall take precedence over the bid.
2. Scope: Contractor shall begin and complete the project described in the
contract documents within the time prescribed in the contract documents. The following
exceptions, alterations, or modifications to the contract documents are incorporated into
this contract:
3. Price & Payment: City shall pay Contractor amounts earned under the
contract. All payments will be made at the times and in the manner provided in the
contract documents.
4. Bond: Contractor shall, within five days after execution of the contract and prior
to doing any work under the contract, furnish bond t~~~~8h~119,in a form and
with a surety satisfactory to City in the penal sum of . ~nditioned upon
the faithful performance of this contract upon the part of the Contractor. -117
..:; -, D
5. Default: A default shall occur under any of the following circumstances:
5.1 If the Contractor fails to begin the work under contract within the time
specified, or fails to perform the work with sufficient workers or equipment or with
sufficient materials to insure the prompt completion of the project, or shall neglect or
refuse to remove materials or perform anew such work as shall be rejected as
defective or unsuitable, or shall discontinue the prosecution of the work.
5.21f the Contractor shall become insolvent or declared bankrupt, or commit any act
of bankruptcy or insolvency, or allow any final judgment to stand against the
Contractor unsatisfied for a period of forty-eight (48) hours, or shall make an
assignment for the benefit of creditors.
5.3 From any other cause whatsoever, shall not carry on the work in an acceptable
manner.
6. Remedies: In addition to the rights and remedies to which the City may be
entitled by law for the enforcement of its rights under this contract, City shall have full
power and authority, without violating this contract, to take prosecution of the work from
the Contractor, and appropriate or use any or all of the materials and equipment on the
ground that may be suitable and acceptable and may cause a contract for the
completion of this contract according to its terms and provisions, or use such methods
G:\pub-wrks\eng\dept-admin\ENGINEER\PROJECT\2D04 Asphalt Crushing Weathers Contract 5 D6.doc
as required for the completion of the contract, in any acceptable manner. All costs and
charges incurred by the City together with the costs of completing the work under the
contract, shall be deducted from any money due or which shall become due the
Contractor. In case the expense so incurred by the City shall be less than the sum
which would have been payable under the contract if it had been completed by the
Contractor, then the Contractor shall be entitled to received the difference less any
damages for delay to which the City may be entitled. In case such expense shall
exceed the sum which would have been payable under the contract, the Contractor and
the surety shall be liable and agree to and shall pay the City the amount of the excess
with damages for delay of performance, if any.
7. Prevailino Waoe Rates: All projects in excess of $50,000.00 require the
Contractor to pay prevailing wage rates. No bid shall be considered unless the bid
contains a statement by the bidder as a part of the bid that the provisions of ORS
279C.800 through 279C.870 Prevailing Wage Rates will be complied with. The
Contractor shall pay a fee equal to one-tenth of one percent (0.1 percent) of price of this
Contract. The fee shall be paid on or before the first progress payment or 60 days from
the date work first begins on the Contract, whichever comes first. The fee is payable to
the Bureau of Labor & Industries and shall be mailed or otherwise delivered to the
Bureau at the following address:
Bureau of Labor & Industries
Wage & Hour Division Prevailing Wage Unit
800 N.E. Oregon Street #32
Portland OR 97232
8. Livino Waoe Rates: If the amount of this contract is $15,000 or more, Consultant
is required to comply with chapter 3.12 of the Ashland Municipal Code by paying a living
wage, as defined in this chapter, to all employees performing work under this contract
and to any subcontractor who performs 50% or more of the service work under this
contract. Consultant is also required to post the attached notice predominantly in areas
where it will be seen by all employees.
The Contractor shall fully comply with the provisions of ORS 279.348 through
279.365 pertaining to prevailing wage rates.
CONT~T~R fl'
BY:~/~~
Its: n ~;7/ .a:c-U"r
CITY OF ASHLAND
By: ~ ~__ICJ- sJ~#~
Lee Tuneberg
Interim City Administrator
BY:.\ ~ (/tJILZ-
DGrrtment Head Date: b It ~ / /J.{;
Coding:
(For City use only)
By:
Its:
G:\pub-wrks\eng\dept-admin\ENGINEER\PROJECT\2004 Asphalt Crushing Weathers Contract 5 06.doc
V~/~O/~VV~ ~~:O~
O'l.LOO:.!:.!.:l:.!':l
A~ANU WA 11:.1'< Ul:.1-' I I'<
I-'Al:il:. l:I:l/l:l:l
Ap~ 21 OS 03148p
Dar'win .. Penn~ Weather's 541-664-7555
,..2
C I T Y' 0 F
ASH'LAND
REQUEST FOR QUOTATIONS
Asphalt located at the Glenview Street asphalt pit. Finished product should be crushed
to a diameter of 1 inch or smaller. Water will be supprled by the City of Ashland street
Department .
Please indicate your quotation for each of the following items as indicated below.
Amount
No.1 .
;ER.i:~~F:~'~ril~'~
Signature .
~~,~ 0. W&A-r~4rQJ' Address: ",,0 'Roc y v..J "'1
. c:..e:..v T (Z. p..L. 'PI,) (}/...,...-
'PR~~/~~,v"- 0(:4 &f750~
Ime
W! A--rJJ6~fCtc(.5IIlp($, ~jL
l,;ORIP.~ ' ,Phone: ::stI-1 - f#t;,4 ".. ~36d
To 'Blb COM P Lt= ,E P OrJ oR.
.:rLANE: IO~ 2.00'"
L31:: F eRr;-
SClVot Division Tel: 541/48&.5313
20 E. Malrl Street Fax: 541~2S2I
Ashlillncl, 0I'egan 17520 TTY: eoonas-aoo
_.II!1hlllld Il'L . .
G:~"'" i-IIdmin\ENGlIllEER'f'ROJECNOO6 A!lphal CtllSI'lIng AFQ far Snet Cllpt 4 lI6.~
. If. ,.
....~
. CITY OF ASHLAND, OREGON
City of Ashland
LIVING
Employees must be paid a
living wage:
of business of their employer, cafeteria plans (including
if the employer has ten or childcare) benefits to the
more employees, and has amount of wages received by
received financial assistance the employee.
~ For all hours worked under a for the project or business
from the City of Ashland in ~ Note: "Employee" does not
service contract between their excess of $16,379. include temporary or part-time
employer and the City of employees hired for less than
Ashland if the contract ~ If their employer is the City of 1040 hours in any twelve-
exceeds $16,379 or more. Ashland including the Parks month period. For more
~ For all hours worked in a and Recreation Department. details on applicability of this
policy, please see Ashland
month if the employee spends ~ In calculating the living wage, Municipal Code Section
50% or more of the employers may add the value 3.12.020.
employee's time in that month of health care, retirement,
working on a project or portion 401 K and IRS eligible
For additional information:
Call the Ashland City Administrator's office at 541-488-6002 or write to the City Administrator,
City Hall, 20 East Main Street, Ashland, OR 97520 or visit the city's website at www.ashland.or.us.
Notice to Employers: This notice must be posted predominantly in areas where it can be seen by all
employees.
CITY'Of
ASHLAND
--..-------- - .~_._-'-~~