HomeMy WebLinkAbout2006-096 Contract - Mountain View Paving
C I T Y OF CONTRACTOR: Mountain View Paving
ASHLAND CONTACT: Kris Meyer
20 East Main Street ADDRESS: 2560 E. Main Street, Ashland, OR 97520
Ashland, Oregon 97520
Telephone: (541) 488-6002 TELEPHONE: (541) 488-7745
FAX: (541) 488-5311
FAX: (541)488-3852
DATE AGREEMENT PREPARED: June 20, 2006
BEGINNING DATE: June 21,2006 COMPLETION DATE: June 30, 2006
COMPENSATION: $4,400.00 - Per proposal dated 06/07/2006
SERVICES TO BE PROVIDED: Contractor to remove 1110 sq feet of old asphalt from inside the hanger, regrade and re-roll
base, and pave with 3.0" compacted asphalt. Location: Ashland Airport, Old Green Hanger
ADDITIONAL TERMS:
Contract for WORK less than $25,000
CITY AND Contractor AGREE:
1. All Costs bv Contractor: Contractor shall, at its own risk and expense, perform the work described above and, unless othGrwise
specified, furnish all labor, equipment and materials required for the proper performance of such work.
2. Qualified Work: Contractor has represented, and by entering into this contract now represents, that all personnel assigned to the work
required under this contract are fully qualified to perform the work to which they will be assigned in a skilled and workerlike manner and, if
required to be registered, licensed or bonded by the State of Oregon, are so registered, licensed and bonded. Contractor must also
maintain a current City business license.
3. Completion Date: Contractor shall start performing the work under this contract by the date indicated above and completl3 the work by
the completion date indicated above.
4. Compensation: City shall pay Contractor for work performed, including costs and expenses, the sum specified above. Orce work
commences, invoices shall be prepared and submitted by the tenth of the month for work completed in the prior month. Payments shall be
made within 30 days of the date of the invoice. Should the contract be prematurely terminated payments will be made for w:)rk completed
and accepted to date of termination. Compensation under this contract, including all costs and expenses of Contractor, is limited to
$25,000.00 and City shall not be obligated to pay any sum in excess of $25,000.00 unless a separate written contract is entered into by
City.
5. Ownership of Documents: All documents prepared by Contractor pursuant to this contract shall be the property of City.
6. Statutory Requirements: ORS 279C.505, 279C.515, 279C.520, and 279C.530 are made part of this contract.
7. Livinq Waqe Requirements: If the amount of this contract is $15,964 or more, and Contractor is not paying prevailing wane for the work,
Contractor must comply with chapter 3.12 of the Ashland Municipal Code by paying a living wage, as defined in this chapter, to all
employees performing work under this contract and to any subcontractor who performs 50% or more of the work under this contract.
Contractor must post the attached notice predominantly in areas where it will be seen by all employees.
8. Indemnification: Contractor agrees to defend, indemnify and save City, its officers, employees and agents harmless from any and all
losses, claims, actions, costs, expenses, judgments, subrogations, or other damages resulting from injury to any person (including injury
resulting in death,) or damage (including loss or destruction) to property, of whatsoever nature arising out of or incident to the performance
of this contract by Contractor (including but not limited to, Contractor's employees, agents, and others designated by Contractor to perform
work or services attendant to this contract.) Contractor shall not be held responsible for any losses, expenses, claims, subrogations,
actions, costs, judgments, or other damages, directly, solely, and approximately caused by the negligence of City.
9. Termination: This contract may be terminated by City by giving ten days written notice to Contractor and may be terminated by
Contractor should City fail substantially to perform its obligations through no fault of Contractor.
10. Independent Contractor Status: Contractor is an independent contractor and not an employee of the City. Contractor shall have the
complete responsibility for the performance of this contract. Contractor shall provide workers' compensation coverage as required in ORS
Ch 656 for all persons employed to perform work pursuant to this contract and prior to commencing any work, Contractor srall provide City
with adequate proof of workers' compensation coverage. Contractor is a subject employer that will comply with ORS 656.017.
11. Insurance: Contractor shall, at its own expense, at all times during the term of this agreement, maintain in force a comprehensive
general liability policy including coverage for contractual liability for obligations assumed under this Contract, blanket contractual liability,
products and completed operations, owner's and contractor's protective insurance and comprehensive automobile liability including owned
and non-owned automobiles. The liability under each policy shall be a minimum of $500,000 per occurrence (combined singlle limit for
bodily injury and property damage claims) or $500,000 per occurrence for bodily injury and $100,000 per occurrence for property damage.
Liability coverage shall be provided on an "occurrence" not "claims" basis. The City of Ashland, its officers, employees and agents shall be
named as additional insureds. Contractor shall submit certificates of insurance acceptable to the City with the signed contract prior to the
commencement of any work under this agreement. These certificates shall contain provision that coverages afforded under the policies
cannot be canceled and restrictive modifications cannot be made until at least 30 days prior written notice has been given to City. Each
certificate of insurance shall provide proof of required insurance for the duration of the contract period.
12. Assiqnment and Subcontracts: Contractor shall not assign this contract or subcontract any portion of the work without the written
consent of City. Any attempted assignment or subcontract without written consent of City shall be void. Contractor shall be fully responsible
for the acts or omissions of any assigns or subcontractors and of all persons employed by them, and the approval by City of any
assignment or subcontract shall not create any contractual relation between the assignee or subcontractor and City.
CONTR~;0R'
BY b~ ~~--
J / Signature
M3L fJi tt~~
Print Nam
TITLE S~tA J rv
&hb/~&
I I
FederallD # 4/ -/75 3/5 ~
CCB Name 1JIl8~; fIt-i..J ?tW/j
CITY OF ASHLAND:
A..L /( /'/
BY ~~
FINANCE DIRECT<nt
OR
BY
CITY ADMINISTF:ATOR
DATE ~/IO~y,
DATE
CONTENT REVIEW~ \c"t' '1\\~~
CITY DEPARTMENT HEAD
~-2u-cc.a
DATE
1 JiL.
I'
ACCOUNT # 7 ( C tf/ t3 ;:z-rj-' C & GO?;? ,;L-C
PURCHASE ORDER # t:6~ f? 7 ;?--
(for City purpos,os only)
CCB#
132551
City of Ashland - Business License # 'B/).. ooZ08 I,t1
* Insurance Certificates and a completed IRS W-9 form must be submitted with signed contract.
Revised 4-27-05
JUN-30-2006 10:48A FROM:MOUNTAIN VIew PAVING 5414883852
TO: 5522304
P.l
. MOUNTAIN VIEW PAVING, INC.
. , 2560 E. MAIN STREET
ASHLAND. OREGON 97520
PK. (541) ~"46
FAX (541) 488-3852
INVOICE
I
p..e.TE
INVOICE: NO-
61301.:1.1)06
ISIS
BilL TO:
CITY OF ASHLAND
~ N MOUNT AIN
ASBLAND OR. 91520
~: D~ 'PEtERS.
ASBLAND AIBPOR,T. 1.110 SQtJARi FEET.
'N Quanti'
\ rece\Pt. ~er~/returneo
- " ("It l"eceNe
r',YJ \ I' " \\5t
t.:acr. ?ac\<.\ng cttEcKONe. '".
,-..' KoNe o~pprr ie'"' -
cyf:C \" eN ,-. /
~\ de I\) '.' 000 I1U\ ')0
o P ,de\\\}erj , _--
OIIW)\e.e. m~s) Rea5UlI-._. -
R~\l..Ifned \\e ~
~ea~OOe_~ ~ . - \
Signatl..lre ~ r '
.p\e ~ 5
/
I
(JOb
7'
rIt8nk you!
?BUlF. Meyer!
TOTAL
S4,4:4(}.09
BALANCE DUI:
$4.440,00
. CITY OF ASHLAND, OREGON
City of Ashland
LIVING
ALL employers described
below must comply with City
of Ashland laws regulating
payment of a living wage.
~..,
Employees must be paid a
living wage:
'Y For all hours worked under a
service contract between their
employer and the City of
Ashland if the contract
exceeds $15,964 or more.
" For all hours worked in a
month if the employee
spends 50% or more of the
employee's time in that month
working on a project or
portion of business of their
~per hour effective Junle 30, 2004
(Increases annually every Jurle 30 by the
Consumer Price Index)
employer, if the employer has
ten or more employees, and
has received financial
assistance for the project or
business from the City of
Ashland in excess of
$15,964.
y If their employer is the City of
Ashland including the Parks
and Recreation Department.
, In calculating the living wage,
employers may add the value
of health care, retirement,
401 K and IRS eligible
cafeteria plans (Including
childcare) benefits to the
amount of wages received by
the employee.
y Note: "EmploYE!e" does not
include temporary or part-
time employees hired for less
than 1040 hours in any
twelve-month pE~riod. For
more details on applicability
of this policy, plElase see
Ashland Municipal Code
Section 3.12.020.
For additional information:
Call the Ashland City Administrator's office at 541-488-6002 or write to the City Administrator,
City Hall, 20 East Main Street, Ashland, OR 97520 or visit the city's website at www.ashland.or.us.
Notice to Employers: This notice must be posted predominantly in areas where it can be seen by all
employees.
CITY Of
ASJHLAND
A
REQUISITION FORM
CITY OF
'1\..51-1 LAN D
THIS REQUEST IS A:
D Change Order(existing PO #
Date of RequE~st: 120 ~ IoJ O~
Required Date of Delivery/Service: I J4St4 P I
Vendor Name
Address
City, State, Zip
Telephone Number
Fax Number
Contact Name
\'\t'\ () LA tv T"'\ ) ~ U l ~ W -::p" ,,1 1 t-J ~
2.. S (PO E 1'\"'\ tl\ t I\J 5TR.t= er-
ASH LlArx;o (:) K.. '1}S,-2-G
_S-q \ &..t 88't-7Ci S
SLt l 468 38 5~L.
j..{ R is VY1~ YG 12.'
SOLICITATION PROCESS
Small Procurement o Sole Source o Invitation to Bid
i- Less than $5,000 o Written findings attached (Copies on file)
Quotes (Optional) o Quote or Proposal attached
L- a \..{ C'.J'~~ Cooperative Procurement o Reauest for Propli)sal
o State of ORIWA contract (Copies on file)
Intermediate Procurement o Other government agency contract 0 Special I Exempt
o (3) Written Quotes 0 Copy of contract attached 0 Written findings all ached
(Copies attached) 0 Quote or Proposal attached
0 Contract # 0 Emeraencv
o Written findings al1ached
o Quote or Proposal attached
Description of SERVICES
~~Vl'\O\} E A<:; P h.::llt- -fi2CJ,"n t N!:' t ~ e e F t-Jjq~t::'~
KE~(2.;qC>E t~~I::> 0).1'\ yrlel "BM~e.
:r .q\) i2 w.!311 ~)."" P '.Xl-!.<.....~ 14~ (tl;? 1 k
o Per attached PROPOSAL
Item # Quantity
Unit
Description of MATERIALS
Unit Price
Total Cost
Project Number _ _ _ _ _ _ - _ _ _
Account Number f 1 Q - f:!:'?1- ~~ _t;Q~~ ~(j
. Items and services must be charged to the appropriate account numbers for the financials to ref/ect the actual expenditures accurately.
o Per attached QUOTE
By signing this requisition form, I certify that the information provided above meets the City of Ashland public contracting requirements,
and the documentation;:e P~d u~!..equest.
Employee Slgnalure: ~ ~ SupervlsorlDept. Head Signature: ~~ ~
G: Finance\ProcedureIAP\Forms\8_Requisition form revised.doc
Updated on: 5/1712006
Page No.
of
Pages.
I'A( \ MOUNTAIN VIEW PAVING, INC.
~ 2560 E. MAIN STREET
.... I . ", c. ASHLAND, OREGQN 9752Q
PH. (541} 488-7745
FAX (541) 488-3852
PHONE.,., '. .'
. - . i,' 5~~~2292
tATE06/07/~
TO
'CITY OF ASHLAND
90 N. MOUNTAIN
..........'...... \'. ,......~~1~,..OR.97520
A'f"tNtf...l)~~~.'ijt;~. '
'. . . ."".- ,,,-,...', '.
JOB NAME I.lOCATION
A;SKAN6AIRPORT
ASPHALT PAVING:
1 REMOVE 1110 SQ. FEET OF OLD ASPHALT.
2 REGRADE AND RE-ROLL BASE.
3 PAVE WITH 3.0" COMPACTED ASPHALT.
WE PROPOSE hereby to furnish material and labor - complete in accordance with the above specifications. for the ~;um of:
FOUR THOUSAND FOUR HUNDRED FORTY AND 00/100 dollars ($ $4,440.00
).
Payment to be made as follows:
TOTAL DUE UPON COMPLETION OF PROJECT.
All material is guaranteed to be as specified. All work to be completed in a professional manner
according to standard practices. Any alteration or deviation from above specifications involving
additional work and extra costs will become an extra charge over and above the estimate. If sub-
base and/or base is prepared by others. guarantee is limited to workmanship, All agreements are
~ontingent upon strikes. accidents, inclement weather, or other delays beyond OUf control.
Employees of contractor are covered by state insurance laws. Terms: payment in full on
completion of project, unless other arrangements are made in writing. A 1.5% per month finance
charge will be added on all past due accounts (an annual percentage rate of 18%). If litigation is
instituted arising directly out of this proposal, the prevailing party shall be entitled to reasonable
attorney's fees and costs incurred, CCB# 59920.
/
/ /~ ?7t;?
Authonzed
Signature
Note: This proposal may be
withdrawn by us if not accepted within
30
days.
ACCEPTANCE OF PROPOSAL - The above prices. specifications
and conditions are satisfactory and are hereby accepted. You are authorized Signature
to do the work as specified. Payment will be made as outlined above.
Date of Acceptance:
Signature
rom: line \.:osta At: cramer & Giles Insurance, Inc. FaxlD: 541-485-3946 To: CITY OF ASHLAND
Date: 6r.~0I2006 02: 19 PM Page::2 of:
ACORD. CERTIFICATE OF LIABILITY INSURANCE OP 10 6~ DATE (MMIDD/VYYY)
MOUN'JI!-6 06/30/06
PRODUCER ,\ THIS CERTIFICATE IS ISSUED AS A MATTEf;l OF INFORMATION
ONLY AND CON FellS NO R1GKTS UPON THIE CERTIFICATE
Cramer & Giles Xns., Xnc. HOLDER. THIS CERTIFICATE DOES NOT AM.END, EXTEND OR
P. O. Box 70206 I AL TE/Ir THE COVERAGE A......ORDED BY THE: POt.lCIES BELOW.
Eugene OR. 9i401.
Phone: 541-485-6633 Fax: 541-485-3946 JNSURERSAFFORDlHG COVERAGE NAlC#
INSURED INSURER A
Ore.n hI.'t.oa.obil. 1x\aur.anc.. C4 .~
INSURER B &AIF corporation
Mountain view Paving, I:.nc. INSURER C
2560 E Main st. INSURER D
Aahland OR 97520
INSURER E
COVERAGES
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED NOTWITHSTANDING
ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTAACT OR OTHER DOCUMENT WITH RESPECT TO WHICH T1-1IS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN. T1-1E INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO AlL THE TERMS. EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES .4GGREG4iE ~ IMITS SHOWN MA l' H4l~ BEEN RED!XED BY ,"l'l,(D CLAIMS
I"~""" mRll POLIC."( ~ER LIMITS
IoTR ~ OF IN~CE I)"TC lMM/OOtN', OA TE \VIMIOO1YY)
GENERAl. UABILIlY EA.CH OCCURRENCE $ 1,000,000
- 09/25/05 09/25/06 ::C''''':~'=-~ ":''''' , ,:0--' --
A X COMMERCIAL GENERAL LIABILITY C04154211 PREMISES (Ea occurence) $ 100 ,000
I CLAIMS MADE ~ OCCUR MED EXP (Anyone person) $ 5,000
PERSONAL & ADV NJURY $1,000,000
- -_.
GENERAl AGGREG-ATE $2,000,000
GENt AGGREGATE LIMIT APPLIES PER PRODUCTS - COMP/OP AGG $2,000,000
I POLICY n I]g,. nLOC
AUTOMOBILE LIAB/LIlY COMBINED SINGLE. LIMIT
- $
ANY AUTO (Ea eccldent)
-
ALL OWlliED AUTOS 80DIL Y INJURY
---:- $
SCHEDULED AUTOS (Par person)
c-- --
HIRED AUTOS \ BODIL l' .,)~~tJI'i'Y
f--- $
NON-OWNED AUTOS (Per aCCident)
l---- I PROPERTY DAMAGE
(Per aCCident) $
GARAGE LlABIlIlY AUTO ONL Y - EA A:::CIDENT $
==1 ANY AUTO OTHER THAN EAACC $
AUTO ONLY AGG $
EXCESSlUMBRELLA LlABILIlY EA.CH OCCURRENCE $
~OCC,',I'C o CLA.lMS MACE I AGGREGA;'C $
$
q DEDUCTIBLE I $
RETENTION $ I $
WORKERS COMPENSATION ANO X ITO'R'y L.IMr'rs I IVE;r
B EMPLOYERS' LIASILIlY 496578 10/01/05 10/01/06 E L EACH ACCIDENT $ 500000
ANY PROPRIETORJPAR1NERiEXECUTIVE
OFFICER/MEMBER EXCLUDED? E l DISEA.SE - EA EMPLOYEE $ 500000
If yes, ooscribe ~.. E L. DISEASE - POLICY LIMIT $ 500000
-~'- SPECiAl PROVISIONS below
On-le\
OIiSCRIPl1ON OF OPERATIONS I LOCATIONS I VEHICLES I EXCLU1IIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS
Rl!: : ASHLAND AIRPORT
CERTIFICATE HOLDER
ASHLAND
CANCELLATION
SHOULD /lNY OF TIiE ABOYE DESCRIBED POLICIES BE ClINCELLED BEFORE THE EXPIRATION
DATE ~OF, THE I6"SUtNG INSUIll:~ WILL I:NOEAVOR TO 11M/(. 30 DAYS WRtITEN
NOTICE "tQ"tHE CERN'lUl.TE HOLOE~ NAMED "tQ"l"HE LIOFT, WT FAILURE "to DO SO Si-\N.L
JMPOSE ND DSLIGA1JON OR LIABILJTY OF Am KIND UPON THE INSURER, JTS AGENTS OR
CXTY OF ASHLAND
90 N. MOUNTAIN
ASHLAND ot\. 9752Q
i>ACORD CORPORATION 1988
ACORD 25 (2001/081
r~'
C IT Y 0 F CiTY FiECORDER'S COpy
ASHLAND
Page 1 / 1
20 E MAIN ST.
ASHLAND, OR 97520
(541) 488r5300
6/20/2006
E;~~6~6\t'
VENDOR: 000111
MOUNTAIN VIEW PAVING,INC
2560 EAST MAIN ST
ASHLAND, OR 97520
SHIP TO: Ashland Building Maintenance
(541) 488-5358
90 N MOUNTAIN AVENUE
ASHLAND, OR 97520
FOB Point:
Terms: Payable on receipt
Req. Del. Date: 6/21/2006
Speciallnst:
Req. No.:
Dept.: PUBLIC WORKS
Contact: Dale Peters
Confirming? No
BLANKET PURCHASE ORDER
Ashland Airport Pavinq Project
Contractor to remove 111 0 sq feet of
old asphalt, reqrade and re-roll base,
and pave with 3.0" compacted asphalt.
4,440.00
Contract for Work
Date of Aqreement: June 20, 2006
Beqinninq Date: June 21, 2006
Completion Date: June 30,2006
Insurance required/On file
BILL TO: Account Payable
20 EAST MAIN ST
541-552-2028
ASHLAND, OR 97520
SUBTOTAL
TAX
FREIGHT
TOTAL
4 440.00
0.00
0.00
4,440.00
?c-r I
VENDOR COPY