Loading...
HomeMy WebLinkAbout2006-207 Contract - Architectural Design Works CITY OF ASHLAND CONTRACT FOR PERSONAL SERVICES Contract made on the date specified below in Recital A between the City and Contractor as follows: Recitals: A. The following information applies to this contract: CITY: CITY OF ASHLAND Contractor: Architectural Design Works, Inc City Hall Address: 1105 Siskiyou Blvd. 20 E. Main St. PO Box 1348 Ashland, Oregon 97520 Ashland, OR 97520 (541) 488-6002 FAX: (541) 488-5311 Telephone: 541-488-0719 FAX: 541-488-1336 Date of this agreement: 10/27/06 B: Date RFP 1st Advertised: Beginning Date: 11/1/06 ....l -Proposal opening date: September 29, 2006 Completion Date: rE:I-. _ Jh .;)a:J7 2.2. Contracting officer: DaTe Peters, Facility Maintenance Lead Worker 2.3. Project Name: Design Services to Prepare Bid Documents to Enclose an Existing Covered Metal Storage Building & Construction of Additional Office Project Description: 6.1 Contractor's representative: Jac Nickels, AIA,CSI 8.3. Maximum contract amount: $45,300 B. On the date noted above, City issued a request for proposals (RFP) for services needed by City for the project described above. Contractor submitted a proposal in response to the RFP on the date noted above. C. After reviewing Contractor's proposal and proposals submitted by other offerors, City selected Contractor to provide the services covered by the RFP. City and Contractor agree as follows: 1. Relationship between City and Contractor: Contractor accepts the relationship of trust and confidence established between Contractor and City by this contract. Contractor covenants with the City to perform services and duties in conformance to and consistent with the standards generally recognized as being employed by professionals of Contractor's caliber in the locality of the project. Contractor further covenants to cooperate with City, City's representatives, contractors, and other interested parties in furthering the interests of City with respect to the contracted services. Contractor acknowledges that City is relying on p~~ ("'"R;1 l' '" r Contractor to provide professional services in a manner that is consistent with the interests of City. 2. Definitions: Generally words, terms and phrases used in this contract shall have the meaning ascribed to them in the construction industry, unless the context clearly indicates otherwise. As used in this contract: 2.1. "City" means the City of Ashland, Oregon. 2.2. "Contracting officer" means the person specified in Recital A above or that person's designee. 2.3. "Project" means the project described in Recital A. 2.4. "Work" or "Services" shall mean all labor, materials, plans, specifications, opinions, reports, and other services and products which Contractor is required to provide under this contract. 3. Term: The term of this contract shall commence on the date specified in Recital A above and on the completion date specified in Recital A above, or with thirty (30) days written notice to the other party. 4. Authority of Contractino Officer: The contracting officer shall have the authority to act on behalf of City in the administration and interpretation of this contract. The contracting officer shall have complete authority to authorize services, transmit instructions, receive information, interpret and define City's policies and make other decisions with respect to Contractor's services. 5. Contractor's Services: Contractor shall provide services to City that are described in the RFP. 5.1. In connection with the services described in the RFP, Contractor shall: 5.1.1. Consult appropriate representatives of City to clarify and define City's requirements relative to the services. 5.1.2. Cooperate with other Contractors retained by City in the exchange of information needed for completion of the services and the project. 5.2. Contractor shall commence performance of services after receiving written authorization from the contracting officer for work described in the RFP. Contractor shall perform the services as expeditiously as is consistent with professional skill and care. 5.3. Contractor shall perform the services as an independent contractor in accordance with generally accepted standards in Contractor's profession. Contractor shall be responsible for the professional quality, technical accuracy and the coordination of all services performed by Contractor. Contractor shall, without additional compensation, correct or revise any error or deficiencies in the services that are caused by Contractor's negligence. City's review, approval, acceptance of, or payment for, any of the services shall not be construed to waive any of City's rights under this contract or of any cause of action arising out of Contractor's services. In the event of any breach of this contract by Contractor or negligent performance of any of the services, City's cause of action against Contractor shall not be deemed to accrue until City discovers such breach or negligence, or should have, with reasonable diligence, discovered such breach or negligence. The preceding sentence shall not be construed, however, to allow City to prosecute an action against Contractor beyond the maximum time limitation provided by Oregon law. 5. This contract may be terminated by either party for any reason with thirty (30) days written notice. 6. Assionment of Contractor's Personnel: 6.1. The services covered by this contract shall be rendered by, or under the supervision of the person specified in Recital A above, who shall act as Contractor's representative in all communications and transactions with City. P /t 'Y ;2 ~ tf ~1 6.2. Contractor will endeavor to honor reasonable specific requests of City with regard to assignment of Contractor's employees to perform services if the requests are consistent with sound business and professional practices. 7. Responsibilities of City: 7.1. City will cooperate fully with Contractor to achieve the objectives of this contract. 7.2. City will arrange for access to, and make all provisions for Contractor to enter upon, public and private property as required for Contractor to perform the services. 7.3. The contracting officer will act as liaison between City, Contractor, public agencies, and others involved in the project. 8. Payment: 8.1. City shall pay Contractor for services. No reimbursement will be made for expenses that are not specifically agreed to by the contracting officer. 8.2. Contractor shall submit monthly invoices to City for Contractor's services within ten days after the end of the month covered by the invoice. 8.3. Total payments under this contract or any amendments shall not exceed the sum specified in Recital A above. 9. Compliance with Law: 9.1. This contract will be governed by and construed in accordance with laws of the State of Oregon. Contractor shall promptly observe and comply with all present and future laws, orders, regulations, rules and ordinances of federal, state, City and city governments with respect to the services including, but not limited to, provisions of ORS 279C.505, 279C.515, 279C.520, and 279C.530. 9.2. Pursuant to ORS 279C.520(2) any person employed by Contractor who performs work under this contract shall be paid at least time and a half pay for all overtime in excess of 40 hours in anyone week, except for persons who are excluded or exempt from overtime pay under ORS 653.010 to 653.261 or under 29 U.S.C. Sections 201 to 209. 9.3. Contractor is a .subject employer" as defined in ORS 656.005 and shall comply with ORS 656.017. Prior to commencing any work, Contractor shall certify to City that Contractor has workers' compensation coverage required by ORS Chapter 656. If Contractor is a carrier insured employer, Contractor shall provide City with a certificate of insurance. If Contractor is a self-insured employer, Contractor shall provide City with a certification from the Oregon Department of Insurance and Finance as evidence of Contractor's status. 9.4. If the amount of this contract is $16,936 or more, Contractor is required to comply with chapter 3.12 of the Ashland Municipal Code by paying a living wage, as defined in this chapter, to all employees performing work under this contract and to any subcontractor who performs 50% or more of the service work under this contract. Contractor is also required to post the attached notice predominantly in areas where it will be seen by all employees. 10. Ownership of Documents: All documents prepared by Contractor pursuant to this contract shall be the property of City. To the extent permitted by law, City shall, within the limits of the Oregon Tort Claims Act, defend, indemnify and hold harmless Contractor, its Contractors, agents and employees against all damages, claims, expenses and losses arising out of any reuse of plans, specifications and other documents prepared by Contractor without prior written authorization of Contractor. Contractor may use the project, including design documents, in promotional materials. rAth' ;g .;'Iff t' 11. Records: 11.1. Contractor shall develop and maintain complete books of account and other records on the services, which are adequate for evaluating Contractor's performance. Contractor shall maintain records in such a manner as to provide a clear distinction between the expenditures and revenues related to the project and the expenditures and revenues related to Contractor's other business. 11.2. Contractor's books and records shall be made available for inspection by City at reasonable times, to verify Contractor's compliance with this contract. City shall have the right to request an audit of Contractor's books and records by a certified public accountant retained by City. 12. Indemnification: Contractor shall defend, indemnify and save City, its officers, agents, and employees harmless from any and all claims, actions, costs, judgments, damages or other expenses resulting from injury to any person (including injury resulting in death,) or damage to property (including loss or destruction), of whatsoever nature arising out of or incident to the negligent performance of this contract by Contractor (including but not limited to, the negligent acts or omissions of Contractor's employees, agents, and others designated by Contractor to perform work or services attendant to this contract). Contractor shall not be held responsible for any claims, actions, costs, judgments, damages or other expenses, directly and proximately caused by the negligence of City or other parties who do not have a subordinate contractual relationship with the Contractor. 13. Insurance: 13.1. Contractor shall, at its own expense, at all times during the term of this contract, maintain in force: 13.1.1. A comprehensive general liability policy including coverage for contractual liability for obligations assumed under this contract, blanket contractual liability, products and completed operations and owner's and contractor's protective insurance; 13.1.2. A professional errors and omissions liability policy; and 13.1.3. A comprehensive automobile liability policy including owned and non- owned automobiles. 13.2. The coverage under each liability insurance policy shall be equal to or greater than the limits for claims made under the Oregon Tort Claims Act, ORS 30.260-30.270, with minimum coverage of $500,000 per occurrence (combined single limit for bodily injury and property damage claims) or $500,000 per occurrence for bodily injury and $100,000 per occurrence for property damage. 13.3. Liability coverage shall be provided on an "occurrence" basis. "Claims made" coverage will not be acceptable, except for the coverage required by subsection 13.1.2. 13.4. Contractor shall submit certificates of insurance acceptable to the City with the signed contract prior to the commencement of any work under this agreement. Each certificate shall state that coverage afforded under the policy cannot be cancelled or reduced in coverage cannot be made until at least 30 days prior written notice has been given to City. A certificate which states merely that the issuing company "will endeavor to mail" written notice is unacceptable. Each certificate of insurance shall provide proof of required insurance for the duration of the contract period. 14. Default: 14.1. There shall be a default under this contract if either party fails to perform any act or obligation required by this contract within ten days after the other party gives written notice specifying the nature of the breach with reasonable particularity. If the breach specified in the notice is of such a nature that it cannot be completely cured within the ten day period, no default shall occur if the party receiving the notice begins performance of the act or obligation within the ten day period and thereafter proceeds with . (--~? ~ ~ >) ~ .tf 4j reasonable diligence and in good faith to effect the remedy as soon as practicable. 14.2. Notwithstanding subsection 14.1, either party may declare a default by written notice to the other party, without allowing an opportunity to cure, if the other party repeatedly breaches the terms of this contract. 14.3. If a default occurs, the party injured by the default may elect to terminate this contract and pursue any equitable or legal rights and remedies available under Oregon law. All remedies shall be cumulative. 14.4. Any litigation arising out of this contract shall be conducted in Circuit Court of the State of Oregon for Jackson County. 15. Termination without Cause: 15.1. In addition to the right to terminate this contract under subsection 14.3, either party may terminate by giving the other party written notice thirty (30) days prior to the termination date. 15.2. In addition to the right to terminate this contract under subsection 14.3, Contractor may complete such analyses and records as may be necessary to place its files in order and, where considered necessary to protect its professional reputation, to complete a report on the services performed to date of termination. 15.3. If City terminates the contract under subsection 15.2, Contractor shall be paid for all fees earned and costs incurred prior to the termination date. Contractor shall not be entitled to compensation for lost profits. 16. Notices: Any notice required to be given under this contract or any notice required to be given by law shall be in writing and may be given by personal delivery or by registered or certified mail, or by any other manner prescribed by law. 16.1. Notices to City shall be addressed to the contracting officer at the address provided for the City in Recital A above. 16.2. Notices to Contractor shall be addressed to the Contractor's representative at the address provided for the Contractor in Recital A above. 17. AssiQnment: City and Contractor and the respective successors, administrators, assigns and legal representatives of each are bound by this contract to the other party and to the partners, successors, administrators, assigns and legal representatives of the other party. Contractor shall not assign or subcontract Contractor's rights or obligations under this contract without prior written consent of City. Except as stated in this section, nothing in this contract shall be construed to give any rights or benefits to anyone other than City and Contractor. 18. Modification: No modification of this contract shall be valid unless in writing and signed by the parties. 19. Trade Secrets and Confidential Information: Contractor shall clearly identify specific material within all documents that is considered a trade secret or is otherwise confidential. City agrees, to the extent allowed by state and Federal law, not to disclose to the public any identified trade secrets or confidential material. Contractor waives any and all civil claims arising from any violation of the Uniform Trade Secrets Act (ORS 646.461) if any terial is dis osed to the public if such material is not clearly and specifically identified by Contrac . CITY OF ASHLAND: BY Lf!/ ~ . FINANCE DIRECTO -- BY rA:~ e5 dl;{ 1 BY ~ N\G\c.,fi-L,c;. n _.A Print Name TITLE~ltOtt.I'Jr DATE ~ ~U OCD FederallD #~5~;O ~ DATE CONTENTREVIEW~ DEPARTMENT HEAD ............ DATE ACCOUNT # ~ ~tf? /// g OC? /0 .y::J/ ~ PURCHASE ORDER # c;?7.:2 / / (for City purposes only) *The completed IRS W-9 form and required certificates of insurance must be submitted with the signed contract. Drafted October 2006 FA~ c; e:I f. '1 form W.9 Request for Taxpayer Identification Number and Certification (Rev. January 2003) Department ~ the Treasury IIllemllI Reverue SeNice N Name Q) Cl <<I a. Business name. if different from above c: o 8.~ >0.2 :1 'C .s A.u I City. state. and ZIP code ': Ust accOUlt number(s) here (optionaQ Q) l/l IndividuaV Check appropriate box: 0 Sole proprietor Address (number. street. and apt. or suite no.) o Corporation (2t ;). [i-- " (;1- rJ. V t-t ?I"- t<r ~ Enter your TIN in the appropriate box. For individuals. this is your However. for a resident alien. sole proprietor. or disregarded page 3. For other entities. it is your employer identification n see How to get a TIN on page 3. Note: If the account is in more than one name. see the rt on page 4 for guidelines on whose number to enter. Under penalties of perjury. I certify that: 1. The number shown on this form is correct taxpayer identification number (or I am waiting for a number to be issued to me). and 2. I am not subject to backup withh ing because: (a) I am exempt from backup withholding. or (b) I have not been notified by the Internal Revenue Service ORS) that I a bject to backup withholding as a result of a failure to report all interest or dividends. or (e) the IRS has notified me that I am no 10 subject to backup withholding. and 3. I am a U.S. person Oncl . g a U.S. resident alien). Certification instructions. au must cross out item 2 above if you have been notified by the IRS that you are currently su~t to backup withholding because you" ave failed to report all interest and dividends on your tax return. For real estate transactions. item 2 does not apply. For mortgage interest pfiid. acquisition or abandonment of secured property. cancellation of debt. contributions to an individual retirement arrangement (IRA). a!Xi generaHy. payments other than interest and dividends. you are not required to sign the Certification. but you must provide your corre<;fTIN. (See the instructions on page 4.) Sign I SlgN~ of Here u.s. person ~ I Purpose of Form A person who is required to file an information return with the IRS. must obtain your correct taxpayer identification number (TIN) to report. for example. income paid to you. real estate transactions. mortgage interest you paid. acquisition or abandonment of secured property. cancellation of debt. or contributions you made to an IRA. U.S. person. Use Form W-9 only if you are a U.S. person Oncluding a resident alien). to provide your correct TIN to the person requesting it (the requester) and. when applicable. to: 1. Certify that the TIN you are giving is correct (or you are waiting for a number to be issued). 2. Certify that you are not subject to backup withholding. or 3. Claim exemption from backup withholding if you are a U.S. exempt payee. Note: If a requester gives you a form other than Form W-9 to request your TIN. you must use the requesters form if it is substantially similar to this Form W-9. Foreign person. If you are a foreign person. use the appropriate Form W-8 (see Pub. 515, Withholding of Tax on Nonresident Aliens and Foreign Entities). CertifICation . I security nllTlber (SSN). . . see the Part I instructions on (EIN). If you do not have a number. Date ~ Norvesident alien who becomes a resident alien. Generally. only a nonresident alien individual may use the terms of a tax treaty to reduce or eliminate U.S. tax on certain types of income. However. most tax treaties contain a provision known as a "saving clause." Exceptions specified in the saving clause may permit an exemption from tax to continue for certain types of income even after the recipient has otherwise become a U.S. resident alien for tax purposes. If you are a U.S. resident alien who is relying on an exception contained in the saving clause of a tax treaty to claim an exemption from U.S. tax on certain types of income. you must attach a statement that specifies the following five items: 1. The treaty country. Generally. this must be the same treaty under which you claimed exemption from tax as a nonresident alien. N2. The treaty article addressing the income. 3. The article number (or location) in the tax treaty that contains the saving clause and its exceptions. 4. The type and amount of income that qualifies for the exemption from tax. 5. SuffICient facts to justify the exemption from tax under the terms of the treaty article. fL/AfJA 7 ~( t r Cat. No. 10231X Form W-9 (Rev. 1-20(3) For additional information: Call the Ashland City Administrator's office at 541-488-6002 or write to the City Administrator, City Hall, 20 East Main Street, Ashland, OR 97520 or visit the city's website at www.ashland.or.us. Notice to Employers: This notice must be posted predominantly in areas where it can be seen by all employees. CITY Of ASHLAND Contract for Personal Services, Page 9 of 9 9 ~.~~ 9 /7' -r EVEREST NATIONAL INSURANCE COMPANY Westgate Corporate Center 477 Martinsville Road P.O. Box 830 Liberty Corner, NJ 07938-0830 (800) 438-4375 ARCHITECTS & ENGINEERS PROFESSIONAL LIABILITY INSURANCE POLICY DECLARATIONS THIS IS A "CLAIMS-MADE" POLICY. PLEASE READ YOUR POLICY CAREFULLY. Named Insured: Architectural Design Works, Inc. Policy Number:48AE001166-061 Address of Named Insured: 1105 Siskiyou Boulevard Ashland OR 97520 Policy Period: From: 04/23/2006 To: 04/23/2007 (12:01 a.m. Standard Time at the Address of the Named Insured) Retroactive Date: January 1, 1977 Additional Insureds: Architectural Design Works Renewal of 48AE001166-051 Professional Services: Those services that any insured is legally qualified to perform for others in the Insured's capacity as an architect, engineer, land surveyor, landscape architect, construction manager, scientist, technical consultant, interior designer, land planner, or golf course designer. Limit of Liability - Each Claim - Aggregate $250,000 $500,000 Deductible - Each Claim - Aggregate $2,500 Not Applicable $8,481 Premium Forms and Endorsements: EEO 02 606 02 02-0regon Cancellation & Nonrenewal Provisions EEO 26 503 02 02-Amendatory Endorsement EEO 03 51002 02-Formal Mediation Endorsement EEO 04 513 02 02-Supplemental Payments EEQ 21 55002 02-Pollution Endorsement EEO 03 512 02 02-Deletion Of Deductible For Claims Expense EEO 04 545 09 03-Broadened Definition of Insured EEO 04 531 05 02-Amendatory Endorsement -------<~-R~en~tive EEO 00 519 02 02-Architects And Engineers Professional Liability c= Dated 04/21/2006 ~--------- EDEC 182 ENIC 02 02 Page 1 of 1 Archiiecturral Design Works 1105 Siskiyou Blvd. P.O. Box 1348 Ashland. Oregon 97520 David Richardson AlA Architect Jac Nickels AlA CSI Architect October 5, 2006 Mr. Dick Wanderscheid, Director City of Ashland Department of Electric Utilities 90 North Mountain Avenue Ashland, OR 97520 Re: REVISED FEE PROPOSAL TO PROVIDE ARCHITECTURAL SERVICES TO PREPARE BID DOCUMENTS TO ENCLOSE AN EXISTING COVERED METAL STORAGE BUILDING Dear Mr. Wanderscheid: In response to our meeting with Scott Johnson regarding our fee proposal, we have revised our fee and scope of services to better match your project needs. Our revised fee assumes we are eliminating the cost estimate from our scope of services and that ADW will provide a single set of construction documents for bidding and will not be otherwise involved with the bid phase of this project. . It also assumes that construction administration (CA) will be billed against a fee allowance on an hourly basis and will be limited to observation of construction at key points in the process as mandated by the State of Oregon for construction observation by licensed design professionals. Any additional CA services provided by ADW will be as requested by the City's Project Manager. Should the allowance be expended prior to completion of the project, we would like to negotiate additional fees with the City to continue to provide these services. Our revised fees are as follows: Stipulated Fee Pre-Design, Design and Construction Documents Allowances (to be billed hourly as needed) Construction Administration Allowance Reimbursable Expenses Allowance $40,000.00 $3,000.00 $2,300.00 [:Jii(JlIC::5.:'i-.:~8-0i'!8 l;'l~:: :-l-.~i::'-:",:.'"': :_:-ii.....j!:;:~:':'-l -,,'--' r . ,i \. .-, 1"~' " . Ii. We hope that our revised fee and scope of services meets your project needs. Please call me if you have any further questions or concerns. We look forward to working with you and Scott to get your project going. Jac Nic els, AlA, CSI President CC: File \\I'.tJwseM>rladw data\I'IDW AdministralionlBus-Dev diem PresentalionslAshland Elect Shed Enclosull! RFP\Admin\ASH EUcr COVER-l-REV-l00406.doc rTfV' .ECORDER'S COpy '-' I I . Page 1 / 1 ~A' CITY OF ASHLAND 20 E MAIN ST. ASHLAND, OR 97520 (541) 488-5300 I 11/::-1 r 07211-' VENDOR: 005394 ARCHITECTURAL DESIGN WORKS INC 1105 SISKIYOU BOULEVARD ATTN: JAC NICKELS ASHLAND, OR 97520 FOB Point: Terms: Net Req. Del. Date: 11/1/2006 Speciallnst: SHIP TO: Ashland Electric Department (541) 488-5354 90 N MOUNTAIN ASHLAND, OR 97520 Req. No.: Depl: ELECTRIC Contact: Scott Johnson/Dale Peters Confirming? No THIS IS A REVISED PURCHASE ORDER BLANKET PURCHASE ORDER Architectural desiQn services to enclose an existinQ covered metal storaQe buildinQ utilized by the Electric Department. Pre-DesiQn, DesiQn, and Construction Documents - Not to exceed $40,000 Allowances (to be billed hourly as needed) Construction Administration Allowance $3,000.00, Reimbursable Expenses Allowance $2,300.00 40,000.00 5,300.00 RFP - September 2006 Date of aQreement: 10/27/2006 BeQinninQ date: 11/01/2006 Completion date: 02116/2007 Insurance required/On file City Project ManaQer: Dale Peters BILL TO: Account Payable 20 EAST MAIN ST 541-552-2028 ASHLAND, OR 97520 SUBTOTAL TAX FREIGHT TOTAL 4 VENDOR COpy f~ 3 ~as(~ CITY OF ASHLAND REQUISITION FORM THIS REQUEST IS A: o Change Order(existing PO # Date of Request: , 11/07/20061 Required Date of Delivery/Service: I Vendor Name Addl'8ll City, State, Zip Telephone Number Fax Number Contact Name Arr.hitAr.tll~1 r1A~ign Wnrh. Inr. 11 05 ~i~kiynll / P 0 Any 1348 Ashland OrP.gon 97520 541-488-0719 Fax 541-488-1336 Jac Nickels. AIA.CSI LICITATION PROCESS ~R Procurement Less than $5.000 Quotes (Not reqUIred) ~Procurwnent (3) Written Quotes (Copies attached) Sole Source Written findings attached ~I'IIIIveProcurwnent Stale d ORJWA contract Other government agency contract o Copy d contract attached o Contract # Reaueltfor ~ (Copies on.) e.2iO 1 SDICIIII ExemDt Written finclngs attached Description of 8ERVlCBS 1)~11.c.J ~~ 70 ~ -:ad ~~ '""f'b ~(o~ A*> cltisnDf ~c:Ji!J1L.U1D ~ ~~tr 6,,/J,~ Per Ittac:hed PROPOSAL Item'" QulUltlty Unit Description of MATERIALS Unit Price Total Cost Project Number~~~~!? ~'- ~ A . / p--O cer ~--$ ~ -: ~ o Per Ittac:hed QUOTE Account Number 690.11.18.00.704100 · Items and services must be charged to the appropriate account numbers for the financials to reflect the actual expenditures accuretely. By signing this requisition form, I certify that the information provided above meets the City of AshlErJd public contracting requirements, "Bm~~~ ~J Employee Slgnat . ~ SupervlsorlDept. Head Signature: G: FlrIanceIProcedurelAPlForms\8_Requisitlon form revised UpdatBd on: 1117/2006